Licensor Personnel Iv
Licensor Personnel Iv Sample Clauses
Related to Licensor Personnel Iv
Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement: A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced. B. The use of tobacco or tobacco products on Board property is prohibited by State law. C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond. D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others. E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement. F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District. G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.
Contractor Personnel – Reference Checks The Contractor warrants that all persons employed to provide service under this Contract have satisfactory past work records indicating their ability to adequately perform the work under this Contract. Contractor’s employees assigned to this project must meet character standards as demonstrated by background investigation and reference checks, coordinated by the agency/department issuing this Contract.
Customer Relations A. Actively promote DCP Holding Company in all Marketing, Sales, Public Relations, and Community activity. B. Strategize that the DCP Holding Company product is placed effectively before the public with emphasis on “Agent/Broker” C. Continually monitor the success, quality and effectiveness of DCP Holding Company marketing
DIRECT PERSONNEL EXPENSE 4.1. Direct Personnel Expense of employees engaged on the Project by the ARCHITECT/ENGINEER includes ARCHITECT/ENGINEERS, other engineers, designers, job captains, draftsmen, specification writers and typists, in consultation, research and design in producing Drawings, Specifications and other documents pertaining to the Project, and in services during construction at the site. 4.2. Direct Personnel Expense includes actual cost and of mandatory and customary financial benefits paid.
Personnel Actions Wages, working conditions, and employee benefits shall be established and administered, and personnel actions of every type, including hiring, upgrading, promotion, transfer, demotion, layoff, and termination, shall be taken without regard to race, color, religion, sex, national origin, age or disability. The following procedures shall be followed: a. The contractor will conduct periodic inspections of project sites to insure that working conditions and employee facilities do not indicate discriminatory treatment of project site personnel. b. The contractor will periodically evaluate the spread of wages paid within each classification to determine any evidence of discriminatory wage practices. c. The contractor will periodically review selected personnel actions in depth to determine whether there is evidence of discrimination. Where evidence is found, the contractor will promptly take corrective action. If the review indicates that the discrimination may extend beyond the actions reviewed, such corrective action shall include all affected persons. d. The contractor will promptly investigate all complaints of alleged discrimination made to the contractor in connection with its obligations under this contract, will attempt to resolve such complaints, and will take appropriate corrective action within a reasonable time. If the investigation indicates that the discrimination may affect persons other than the complainant, such corrective action shall include such other persons. Upon completion of each investigation, the contractor will inform every complainant of all of their avenues of appeal.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Customer Relationships The Executive understands and acknowledges that the Company has expended significant resources over many years to identify, develop, and maintain its clients. The Executive additionally acknowledges that the Company’s clients have had continuous and long-standing relationships with the Company and that, as a result of these close, long-term relationships, the Company possesses significant knowledge of and confidential information about its clients and their needs. Finally, the Executive acknowledges the Executive’s association and contact with these clients is derived solely from Executive’s employment with the Company. The Executive further acknowledges that the Company does business throughout the United States and that the Executive personally has significant contact with the Company’s clients and customers solely as a result of Executive’s relationship with the Company.
Access to Personnel Files All employees shall be allowed access to their personnel files during normal working hours for inspection and/or copies of documents which will be provided by the Employer. Such inspection shall be made subject to prior arrangement with the Employer.
Designated Configuration; Trained Personnel State Street and the Fund shall be responsible for supplying, installing and maintaining the Designated Configuration at the Designated Locations. State Street and the Fund agree that each will engage or retain the services of trained personnel to enable both parties to perform their respective obligations under this Addendum. State Street agrees to use commercially reasonable efforts to maintain the System so that it remains serviceable, provided, however, that State Street does not guarantee or assure uninterrupted remote access use of the System.
TEXT MESSAGING WHILE DRIVING In accordance with Executive Order (EO) 13513, “Federal Leadership on Reducing Text Messaging While Driving,” any and all text messaging by Federal employees is banned: a) while driving a Government owned vehicle (GOV) or driving a privately owned vehicle (POV) while on official Government business; or b) using any electronic equipment supplied by the Government when driving any vehicle at any time. All cooperators, their employees, volunteers, and contractors are encouraged to adopt and enforce policies that ban text messaging when driving company owned, leased or rented vehicles, POVs or GOVs when driving while on official Government business or when performing any work for or on behalf of the Government.
