Limitation on Time Extensions Sample Clauses

Limitation on Time Extensions. Any extension of a Completion Deadline allowed hereunder shall exclude any delay to the extent that it: (a) did not impact a the Critical Path for the applicable Completion Deadline, (b) was due to the fault or negligence, or act or failure to act of any DB Contractor-Related Entity, or (c) could reasonably have been avoided by DB Contractor, including by re-sequencing, reallocating or redeploying its forces to other portions of the Work (provided that if the request for extension involves a TxDOT-Caused Delay, DB Contractor shall be entitled to a time extension unless TxDOT shall have agreed, if requested to do so, to reimburse DB Contractor for its costs incurred, if any, in re- sequencing, reallocating or redeploying its forces). In addition, any extension of a Completion Deadline allowed under this Design-Build Contract other than for a TxDOT-Caused Delay, shall exclude any delay to the extent it is concurrent with any other unrelated delay to a Critical Path for which DB Contractor is responsible hereunder. In the event a delay for which the DB Contractor is solely responsible is concurrent with a TxDOT-Caused Delay, DB Contractor shall be entitled to a time extension for the TxDOT-Caused Delay but not to any increase in the Price due to the delay, including any delay or disruption damages. If a delay for which DB Contractor is entitled to a time extension is concurrent with another delay for which DB Contractor is also entitled to a time extension (or which otherwise counts towards a cap on DB Contractor’s responsibility for such delay, such as the 180-day cap for Karst Mitigation Delay), only one of the delays shall be considered for purposes of the Change Order provisions in the Design-Build Contract. If the concurrent delays provide for different relief (i.e. one day of relief for one day of delay versus one day of relief for two days of delay), the delay providing the greater relief to DB Contractor shall apply. In no event shall DB Contractor receive a time extension or credit towards a time extension for more than one delay on a particular day. DB Contractor shall be required to demonstrate to TxDOT’s satisfaction that the change in the Work or other event or situation that is the subject of the Request for Change Order seeking a change in a Completion Deadline has caused or will result in an identifiable and measurable disruption of the Work that has impacted the Critical Path activity (i.e., consumed all available Float and extended the time ...
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Limitation on Time Extensions. Any extension of a Completion Deadline allowed hereunder shall exclude any delay to the extent that it:
Sample 1Sample 2
Limitation on Time Extensions. ‌ Any extension of a Completion Date allowed hereunder shall exclude any delay to the extent that it: 1. Did not impact the Critical Path affecting a Completion Date. 2. Was due to the fault or negligence, or act or failure to act of any Contractor-Related Entity. 3. Could reasonably have been avoided by the DB Contractor, including by re-sequencing, reallocating or redeploying its forces to other portions of the Work provided that if the request for extension involves a District-caused delay, the District shall have agreed, if requested to do so, to reimburse the DB Contractor for its costs incurred, if any, in re-sequencing, reallocating, or redeploying its forces. The DB Contractor shall demonstrate to the District’s satisfaction that the change in the Work or other event or situation, which is the subject of the RCO seeking a change in a Completion Date, has caused or will result in an identifiable and measurable disruption of the Work, which has affected the Critical Path Activity affecting a Completion Date.
Sample 1
Limitation on Time Extensions. Any extension of a Completion Deadline allowed hereunder shall exclude any delay to the extent that it:  Did not impact the Critical Path affecting a Completion Deadline.  Was due to the fault or negligence, or act or failure to act of any Contractor-Related Entity.  Could reasonably have been avoided by the Contractor, including by re-sequencing, reallocating or redeploying its forces to other portions of the Work (provided that if the request for extension involves an Authority caused delay, the Authority shall have agreed, if requested to do so, to reimburse the Contractor for its costs incurred, if any, in re- sequencing, reallocating, or redeploying its forces).  Was concurrent with any other delay for which the Contractor is not entitled to an extension. The Contractor shall be required to demonstrate to the Authority’s satisfaction that the change in the Work or other event or situation that is the subject of a Change Order seeking a change in a Completion Deadline has caused or will result in an identifiable and measurable delay of the Work which has impacted the Critical Path activity affecting a Completion Deadline.
Sample 1
Limitation on Time Extensions. Any extension of a Completion Deadline allowed hereunder shall exclude any delay to the extent that it (a) did not impact a Critical Path, (b) was due to the fault or negligence, or act or failure to act of any Integrator-Related Entity, (c) is concurrent with any other unrelated delay to a Critical Path that is Integrator’s responsibility hereunder, or
Sample 1
Limitation on Time Extensions. Any extension of time shall exclude any delay to the extent that it (a) was due to the delay, breach, default, fault, act, omission, negligence, recklessness, gross negligence or willful misconduct of any member of the Design/Builder Group, or (b) could reasonably have been avoided by Design/Builder or the other members of the Design/Builder Group, including by resequencing, reallocating or redeploying its forces to other portions of the Development Work. Costs incurred for the purpose of mitigating delays as described in (b) above, and not otherwise disallowed hereunder, would be reimbursable.
Sample 1
Limitation on Time Extensions. Any extension of a Completion Deadline pursuant to Section 20 (Relief & Compensation) and this Section 21 (Construction Phase Change Order) shall exclude any delay to the extent that it: (a) did not impact the Critical Path affecting a Completion Deadline; (b) was due to the fault or negligence, or act or failure to act of any Progressive Contractor- Related Entity; or (c) could reasonably have been avoided by the Progressive Contractor, including by resequencing, reallocating, or redeploying forces to other portions of the Work or Site or to other activities unrelated to the Work. The Progressive Contractor shall demonstrate to the Department’s satisfaction that the change in the Work (or other event or situation which is the subject of the Construction Phase Change Order request seeking a change in a Completion Deadline) has caused or will result in an identifiable and measurable disruption of the Work, impacting a Critical Path activity affecting a Completion Deadline.
Sample 1
AutoNDA by SimpleDocs

Related to Limitation on Time Extensions

  • Limitation on Leases Neither the Borrower nor any Restricted Subsidiary will create, incur, assume or suffer to exist any obligation for the payment of rent or hire of Property of any kind whatsoever (real or personal but excluding Capital Leases and leases of Hydrocarbon Interests and firm transportation contracts or arrangements), under leases or lease agreements which would cause the aggregate amount of all payments made by the Borrower and the Restricted Subsidiaries pursuant to all such leases or lease agreements, including, without limitation, any residual payments at the end of any lease, to exceed $25,000,000 in any period of twelve consecutive calendar months during the life of such leases.

  • Limitation on Out of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.

  • Limitation on Transactions If Debentures are issued to the Trust or a trustee of the Trust in connection with the issuance of Trust Securities by the Trust and (i) there shall have occurred any event that would constitute an Event of Default; (ii) the Company shall be in default with respect to its payment of any obligations under the Preferred Securities Guarantee relating to the Trust; or (iii) the Company shall have given notice of its election to defer payments of interest on such Debentures by extending the interest payment period as provided in this Indenture and such period, or any extension thereof, shall be continuing, then (a) the Company may not, and may not permit any Subsidiary to, declare or pay any dividend on, make any distributions with respect to, or redeem, purchase, acquire or make a liquidation payment with respect to, any of its capital stock (other than (1) the reclassification of any class of the Company's capital stock into another class of capital stock, (2) dividends or distributions payable in any class of the Company's common stock, (3) any declaration of a dividend in connection with the implementation of a shareholder rights plan, or the issuance of stock under any such plan in the future, or the redemption or repurchase of any such rights pursuant thereto, (4) payments under the Preferred Securities Guarantee and (5) purchases of the Company's common stock related to the rights under any of the Company's benefit plans for its or its subsidiaries' directors, officers or employees); (b) the Company shall not make any payment of interest, principal or premium, if any, or repay, repurchase or redeem any debt securities issued by the Company which rank pari passu with or junior to the Debentures; provided, however, that the Company may make payments pursuant to its obligations under the Preferred Securities Guarantee; and (c) the Company shall not redeem, purchase or acquire less than all of the outstanding Debentures or any of the Preferred Securities.

  • Limitation on Transfer The Option shall be exercisable only by the Participant or the Participant’s Permitted Transferee(s), as determined in accordance with the terms of the Plan (including without limitation the requirement that the Participant obtain the prior written approval by the Committee of any proposed Transfer to a Permitted Transferee during the lifetime of the Participant). Each Permitted Transferee shall be subject to all the restrictions, obligations, and responsibilities as apply to the Participant under the Plan and this Stock Option Grant Agreement and shall be entitled to all the rights of the Participant under the Plan, provided that in respect of any Permitted Transferee which is a trust or custodianship, the Option shall become exercisable and/or expire based on the Employment and termination of Employment of the Participant. All Shares obtained pursuant to the Option granted herein shall not be transferred except as provided in the Plan and, where applicable, the Management Investor Rights Agreement.

  • LIMITATION ON ACTIVITIES Notwithstanding any provision in this Agreement to the contrary, the Advisor shall not take any action that, in its sole judgment made in good faith, would (i) adversely affect the ability of the Company to qualify or continue to qualify as a REIT under the Code, (ii) subject the Company to regulation under the Investment Company Act of 1940, as amended, (iii) violate any law, rule, regulation or statement of policy of any governmental body or agency having jurisdiction over the Company, its Shares or its other securities, (iv) require the Advisor to register as a broker-dealer with the SEC or any state, or (v) violate the Charter or Bylaws. In the event an action that would violate (i) through (v) of the preceding sentence but such action has been ordered by the Board, the Advisor shall notify the Board of the Advisor’s judgment of the potential impact of such action and shall refrain from taking such action until it receives further clarification or instructions from the Board. In such event, the Advisor shall have no liability for acting in accordance with the specific instructions of the Board so given.

  • Limitation on Rights (a) This Agreement shall not be deemed to create a contract of employment between the Company and the Executive and shall create no right in the Executive to continue in the Company’s employment for any specific period of time, or to create any other rights in the Executive or obligations on the part of the Company, except as set forth herein. This Agreement shall not restrict the right of the Company to terminate the Executive, or restrict the right of the Executive to terminate employment. (b) Subject to the exception for cash severance payments under the Company’s documented severance policy referenced in Sections 3 and 4 above, this Agreement shall not be construed to exclude the Executive from participation in any other compensation or benefit programs in which the Executive is specifically eligible to participate either prior to or following the execution of this Agreement, or any such programs that generally are available to other executive personnel of the Company, nor shall it affect the kind and amount of other compensation to which the Executive is entitled. (c) The rights of the Executive under this Agreement shall be solely those of an unsecured general creditor of the Company.

  • Limitation on Agreements The modifications set forth herein are limited precisely as written and shall not be deemed (a) to be a consent under or a waiver of or an amendment to any other term or condition in the Original Credit Agreement or any of the Loan Documents, or (b) to prejudice any right or rights that Administrative Agent now has or may have in the future under or in connection with the Original Credit Agreement and the other Loan Documents, each as amended hereby, or any of the other documents referred to herein or therein. The Modification Papers shall constitute Loan Documents for all purposes.

  • Limitation on Use COLLEGE and SCHOOL DISTRICT shall use each student education record that he or she may receive pursuant to this CCAP Agreement solely for a purpose(s) consistent with his or her authority to access that information pursuant to Federal and State law, as may be as applicable. (34 C.F.R. § 99.31, 34 C.F.R. § 99.34, and Education Code § 49076.)

  • Limitation on Time to File Claims ANY CAUSE OF ACTION OR CLAIM YOU MAY HAVE ARISING OUT OF OR RELATING TO THESE TERMS OF USE OR THE WEBSITE MUST BE COMMENCED WITHIN ONE (1) YEAR AFTER THE CAUSE OF ACTION ACCRUES; OTHERWISE, SUCH CAUSE OF ACTION OR CLAIM IS PERMANENTLY BARRED.

  • Limitation on Actions 28.1 Except with respect to any indemnification obligations in Article 12, above, or as are otherwise set forth in the Contract, any arbitral proceedings in accordance with Article 23.2, above, arising out of the Contract must be commenced within three years after the cause of action has accrued. 28.2 The Parties further acknowledge and agree that, for these purposes, a cause of action shall accrue when the breach actually occurs, or, in the case of latent defects, when the injured Party knew or should have known all of the essential elements of the cause of action, or in the case of a breach of warranty, when tender of delivery is made, except that, if a warranty extends to future performance of the goods or any process or system and the discovery of the breach consequently must await the time when such goods or other process or system is ready to perform in accordance with the requirements of the Contract, the cause of action accrues when such time of future performance actually begins.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!