Shipments All Products delivered pursuant to the terms of this Agreement shall be suitably packed for shipment in accordance with the Specifications and marked for shipment to Customer’s destination specified in the applicable purchase order. Shipments will be made EXW (Ex-Works, Incoterms 2000) Flextronics’s facility, at which time risk of loss and title will pass to Customer. All freight, insurance and other shipping expenses, as well as any special packing expenses not included in the original quotation for the Products, will be paid by Customer. In the event Customer designates a freight carrier to be utilized by Flextronics, Customer agrees to designate only freight carriers that are currently in compliance with all applicable laws relating to anti-terrorism security measures and to adhere to the C-TPAT (Customs-Trade Partnership Against Terrorism) security recommendations and guidelines as outlined by the United States Bureau of Customs and Border Protection and to prohibit the freight carriage to be sub-contracted to any carrier that is not in compliance with the C-TPAT guidelines.
Loading RPMG shall schedule the loading and shipping of all outbound corn oil purchased hereunder, but all labor and equipment necessary to load trucks and rail cars and other associated costs shall be supplied and borne by Producer without charge to RPMG. Producer shall handle the corn oil in a good and workmanlike manner in accordance with RPMG’s written requirements and normal industry practice. Producer shall maintain the truck and rail loading facilities in safe operating condition in accordance with normal industry standards and shall visually inspect all trucks and rail cars to assure (i) cleanliness so as to avoid contamination, and (ii) that such trucks and railcars are in a condition suitable for transporting the corn oil. RPMG and RPMG’s agents shall have adequate access to the Ethanol Facility to load Producer’s corn oil on an industry standard basis that allows RPMG to economically market Producer’s corn oil. RPMG’s employees shall follow all reasonable safety rules and procedures promulgated by Producer and provided to RPMG reasonably in advance and in writing. Producer shall supply product description tags, certificates of analysis, bills of lading and/or material safety data sheets that are applicable to all shipments. In the event that Producer fails to provide the labor, equipment and facilities necessary to meet RPMG’s loading schedule, Producer shall be responsible for all costs and expenses, including without limitation actual demurrage and wait time, incurred by RPMG resulting from or arising in connection with Producer’s failure to do so.
Delivery Point Once Manufacture of the Products has been completed, Contractor shall be responsible for delivering the Finished Goods FCA, (as defined in Incoterms (2000) published by the International Chamber of Commerce) and to a freight forwarder specified by Company in its Order, or otherwise approved by Company. “Delivery Point” as used in this Agreement shall mean the specific time and location that the Product is delivered to the shipper specified on the Order.
Processing of Items The provision of services shall be governed by the Processor’s Treasury Management Services Agreement, Commercial Account Agreement or other applicable agreements and related service terms (individually and collectively, the “Bank Agreements”), as may be amended from time to time, subject to the prior written consent to any such amendments of a material nature by the Trustee and AmeriCredit, which consents shall not be unreasonably withheld, conditioned or delayed.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Delivery Points The measurement of and tests for quality of Shipper's Gas redelivered at the Delivery Points shall be governed by and determined in accordance with the requirements of the receiving pipeline at each Delivery Point.
Legending of Shares If so requested by Parent, Stockholder agrees that the Shares shall bear a legend stating that they are subject to this Agreement.
Shareholder Account Maintenance a. Maintain all shareholder records for each account in the Trust.
Janitorial Service Landlord shall not be obligated to provide any janitorial services to the Premises or replace any light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises. Tenant shall be solely responsible, at Tenant’s sole cost and expense, for (i) performing all janitorial services, trash removal and other cleaning of the Premises, and (ii) replacement of all light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises, all as appropriate to maintain the Premises in a first-class manner consistent with the first-class nature of the Building and Project. Such services to be provided by Tenant shall be performed by contractors and pursuant to service contracts approved by Landlord. Tenant shall deposit trash as reasonably required in the area designated by Landlord from time to time. All trash containers must be covered and stored in a manner to prevent the emanation of odors into the Premises or the Project. Landlord shall have the right to inspect the Premises upon reasonable notice to Tenant and to require Tenant to provide additional cleaning, if necessary. In the event Tenant shall fail to provide any of the services described in this Section 6.6 to be performed by Tenant within five (5) days after notice from Landlord, which notice shall not be required in the event of an emergency, Landlord shall have the right to provide such services and any charge or cost incurred by Landlord in connection therewith shall be deemed Additional Rent due and payable by Tenant upon receipt by Tenant of a written statement of cost from Landlord.
Monitoring of Servicers (a) The Master Servicer shall be responsible for reporting to the Trustee, the Trust Administrator and the Depositor the compliance by each Servicer with its duties under the related Servicing Agreement. In the review of each Servicer’s activities, the Master Servicer may rely upon an officer’s certificate of the Servicer with regard to such Servicer’s compliance with the terms of its Servicing Agreement. In the event that the Master Servicer, in its judgment, determines that a Servicer should be terminated in accordance with its Servicing Agreement, or that a notice should be sent pursuant to such Servicing Agreement with respect to the occurrence of an event that, unless cured, would constitute grounds for such termination, the Master Servicer shall notify the Depositor, the Trust Administrator and the Trustee thereof and the Master Servicer shall issue such notice or take such other action as it deems appropriate.
