Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
County Responsibilities 5.1 The COUNTY shall designate a COUNTY staff member to act as COUNTY’s Project Manager. It is agreed to by the parties that the COUNTY’s Project Manager will decide all questions, difficulties, or disputes, of whatever nature, which may arise relative to the interpretation of the plans, construction, prosecution and fulfillment of the Scope of Services, and as to the character, quality, amount and value of any work done, and materials furnished, under or by reason of this Agreement. The COUNTY’s Project Manager may appoint representatives as desired that will be authorized to inspect all work done and all materials furnished.
5.2 The COUNTY shall pay in accordance with the provisions set forth in this Agreement.
5.3 The COUNTY retains the right to inspect all work to verify compliance with the contract documents. Such inspection may extend to all or any part of the work and to the manufacture, preparation or fabrication of the materials to be used.
University Responsibilities 4.1 The University will provide a room accommodation to The Resident for a period of one academic year or the portion of the academic year remaining when occupancy begins (limited to the subsequent fall and spring semesters) exclusive of the Winter Recess period unless The Resident is assigned to a facility that remains open during this time or is approved to live on-campus during Winter Recess. Services provided by the University begin on the official check-in dates for the specific area and include access to the assigned building and room.
4.2 In accordance with University policy, the University will provide staff that will help facilitate a living experience that complements the academic mission of the University.
4.3 Exclusive of unanticipated weather events and building system failures that may disrupt service and subject to the availability of applicable resources, the University will provide adequate light, heat, electricity, hot water and telecommunication services (limited to video and internet connection) to residents. Student rooms shall be furnished.
City Responsibilities 2.8.1 CITY shall make available to CONSULTANT all technical data that is in CITY'S possession, reasonably required by CONSULTANT relating to the SERVICES.
2.8.2 CITY shall provide access to and make all provisions for CONSULTANT to enter upon public and private lands, to the fullest extent permitted by law, as reasonably required for CONSULTANT to perform the SERVICES.
2.8.3 CITY shall examine all reports, correspondence, and other documents presented by CONSULTANT upon request of CITY, and render, in writing, decisions pertaining thereto within a reasonable time so as not to delay the work of CONSULTANT.
2.8.4 It is expressly understood and agreed that all work done by CONSULTANT shall be subject to inspection and acceptance by CITY and approval of SERVICES shall not forfeit the right of CITY to require correction, and nothing contained herein shall relieve CONSULTANT of the responsibility of the SERVICES required under the terms of this Contract until all SERVICES have been completed and accepted by CITY.
Personal Responsibility The Participant and his/her parent(s) or legal guardian(s) certify that Participant has no physical or mental condition that precludes him/her from participating in the Activities and that he/she is not participating against medical advice.
INSURANCE AND PROOF OF FINANCIAL RESPONSIBILITY Contractor understands and agrees that financial responsibility for claims or damages to any person, or to Contractor’s employees and agents, shall rest with the Contractor. Contractor and its subcontractors shall effect and maintain any insurance coverage, including, but not limited to, Workers’ Compensation, Employers’ Liability, General Liability, Contractual Liability, Automobile Liability and Umbrella Liability to support such financial obligations. The indemnification obligation, however, shall not be reduced in any way by existence or non-existence, limitation, amount or type of damages, compensation, or benefits payable under Workers’ Compensation laws or other insurance provisions. The minimum limits of insurance required of the Contractor by MPS shall be: Workers’ Compensation Statutory Limits Employers’ Liability $100,000 per occurrence General Liability $1,000,000 per occurrence/$2,000,000 aggregate Auto Liability $1,000,000 per occurrence Umbrella (excess) Liability $1,000,000 per occurrence The Milwaukee Board of School Directors shall be named as an additional insured under Contractor’s and subcontractors’ general liability insurance and umbrella liability insurance. Evidence of all required insurances of Contractor shall be submitted electronically to MPS via its third party vendor, EXIGIS Risk Management Services. Waivers and exceptions to the above limits will be in the sole discretion of MPS and shall be recorded in the EXIGIS system, which records are incorporated into this Contract by reference. The certificate of insurance or policies of insurance evidencing all coverages shall include a statement that MPS shall be afforded a thirty (30) day written notice of cancellation, non-renewal or material change by any of Contractor’s insurers providing the coverages required by MPS for the duration of this Contract.
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
COUNTY’S RESPONSIBILITIES A. A County program liaison will monitor the submission of all correspondence required in this Agreement, including, but not limited to:
1. Quarterly Treatment Reports;
2. Financial reports such as annual budgets, cost allocation plans, and cost reports;
3. Incident reports;
4. Outcome data;
5. Monthly XXXXX Reports
6. Other requested reports
B. A County program liaison may visit Contractor during the contract term. The visits shall be for the purpose of reviewing any aspect of Contractor’s program operations. The visit may include, but is not limited to:
1. Review all pertinent participant records.
2. Conduct appropriate interviews/discussions with participants served by Contractor.
3. Review and monitor all correspondence and reports submitted by Contractor related to Contractor’s services provided under this Agreement.
4. Meet with appropriate program management and operations staff.
5. Conduct site visit(s) to Contractor’s program(s) at least once during the term of the Agreement to review all aspects of program operations. Site visit(s) may include a review of Contractor’s programmatic and fiscal documentation related to required reports on services specified in the Exhibits.
a. Provide a written site review report documenting areas of compliance and any necessary corrective action(s) required.
6. A County program liaison may attend an organized activity of a selected component or selected components of Contractor’s program(s) at least once during the contract term.
C. AODS will conduct periodic mandatory treatment provider meetings with representatives of all contracted service providers and appropriate staff.
D. Provide ongoing technical assistance as needed.
E. AODS shall act as intermediary on behalf of each contracted alcohol and drug service provider in the submission of the California Outcomes Measurement System (CalOMS) data submissions to the State of California.
I. GENERAL ADMINISTRATIVE REQUIREMENTS
A. Attend each of the following meetings:
1. Contractor shall attend periodic mandatory meetings; and
2. Drug and Alcohol Information System for You (DAISY) User Group meeting.
3. Other meetings as required by the County
B. Contractor shall acknowledge the San Mateo County Alcohol and Other Drug Services (AODS) and/or the County of San Mateo as a funding source on newly developed promotional materials.
C. Subcontracting requirements:
1. Pursuant to paragraph 12 of the body of this Agreement, Contractor may subcontract for provision of services described in this Agreement with written approval of the Director of the Human Services Agency or her designee. If Contractor subcontracts for any services under this Agreement, Contractor will guarantee that any and all subcontractors have and maintain the same level of insurance coverage required of the Contractor under this Agreement. Contractor and County will be listed as additional insured on all applicable insurance of subcontractor.
Department Responsibilities The use of sick leave may properly be denied if these procedures are not followed. Abuse of sick leave on the part of the employee is cause for disciplinary action. Departmental approval of sick leave is a certification of the legitimacy of the sick leave claim. The department head or designee may make reasonable inquiries about employee absences. The department may require medical verification for an absence of three (3) or more working days. The department may also require medical verification for absences of less than three (3) working days for probable cause if the employee had been notified in advance in writing that such verification was necessary. Inquiries may be made in the following ways:
1. Calling the employee's residence telephone number or other contact telephone number provided by the employee if telephone notification was not made in accordance with departmental sick leave call-in guidelines. These inquiries shall be subject to any restrictions imposed by the employee under Section 14.4.a.
2. Obtaining the employee's signature on the Absence/Overtime Record, or on another form established for that purpose, as employee certification of the legitimacy of the claim.
3. Obtaining the employee's written statement regarding the sick leave claim and duration.
4. Requiring the employee to obtain a physician's certificate or verification of the employee's illness, date(s) the employee was incapacitated, and the employee's ability to return to work, as specified above.
5. In absences of an extended nature, requiring the employee to obtain from their physician a statement of progress and anticipated date on which the employee will be able to return to work, as specified above. Department heads are responsible for establishing timekeeping procedures which will insure the submission of a time card covering each employee absence and for operating their respective offices in accordance with these policies and with clarifying regulations issued by the Office of the County Administrator. To help assure uniform policy application, the Director of Human Resources or designated management staff of the County Human Resources Department should be contacted with respect to sick leave determinations about which the department is in doubt.
School Responsibilities Pursuant to §1002.33(8)(e), F.S., the School shall be dissolved under the provisions of law under which the School was organized. Student records and copies of all administrative, operational, and financial records of the School shall be provided to the Sponsor on the date the termination/non-renewal takes effect.
