The Contractor must 16.1.1. treat all Authority Protected Information as confidential and safeguard it accordingly, implementing appropriate technical and organisational measures to protect Authority Protected Information against disclosure;
16.1.2. only use the Authority Protected Information for the purposes of performing its obligations under the Framework Agreement;
16.1.3. only disclose the Authority Protected Information to such Contractor Representatives that are directly involved in the performance of the Framework Agreement and need to know the information; and
16.1.4. not disclose any Authority Protected Information without the prior written consent of the Authority.
Conditions to the Obligations of Each Party The obligations of the Company, Parent and Merger Sub to consummate the Merger are subject to the satisfaction or waiver (where permissible) of the following conditions:
Payroll Records Contractors and Subcontractors must keep original payrolls or transcripts subscribed and affirmed as true under the penalties of perjury as required by law. For public works contracts over $25,000 where the Contractor maintains no regular place of business in New York State, such records must be kept at the work site. For building services contracts, such records must be kept at the work site while work is being performed.
Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager.
7.2.2 The Contractor’s Project Manager shall be responsible for the Contractor’s day-to-day activities as related to this Contract and shall meet and coordinate with County’s Project Manager and County’s Contract Project Monitor on a regular basis.
Personnel Equipment and Material Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the reasonable opinion of County, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the Project when so instructed by County. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than County. Engineer may not change the Project Manager without prior written consent of County.
Contractor Project Manager The Contractor Project Manager shall serve, from the Effective Date, as the Contractor project manager and primary Contractor representative under this Agreement. The Contractor Project Manager shall (i) have overall responsibility for managing and coordinating the performance of Contractor’s obligations under this Agreement, including the performance of all Subcontractors; and (ii) be authorized to act for and bind Contractor and Subcontractors in connection with all aspects of this Agreement. The Contractor Project Manager shall respond promptly and fully to all inquiries from the JBE Project Manager.
HHSC and Contractor Agreements HHSC and Contractor hereby agree:
A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect.
B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC.
C. That this Contract may be assigned to a state agency or agencies.
D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances:
1. to correct an obvious clerical error in the Contract;
2. to incorporate new or revised federal or state statutes, rules or policies;
3. to comply with a court order or judgment; and
4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State.
E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit.
F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract.
G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat:
1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and
2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees.
H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship.
I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40.
J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract.
K. That in compliance with §2262.003, Texas Government Code:
1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract;
2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and
3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit.
L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program.
M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination.
N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires.
O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas.
P. That this Contract may be terminated by:
Conditions to Obligations of Each Party The respective obligations of each Party to perform this Agreement and consummate the Merger and the other transactions contemplated hereby are subject to the satisfaction of the following conditions, unless waived by both Parties pursuant to Section 11.6:
Subcontractor Insurance In accord with Good Utility Practice, each Interconnected Entity shall require each of its subcontractors to maintain and provide evidence of insurance coverage of types, and in amounts, commensurate with the risks associated with the services provided by the subcontractor. Bonding of contractors or subcontractors shall be at the hiring Interconnected Entity’s discretion, but regardless of bonding, the hiring principal shall be responsible for the performance or non- performance of any contractor or subcontractor it hires.
Contractor’s Equipment Payment for required equipment owned by the Construction Manager or an affiliate of the Construction Manager will be based solely on an hourly rate derived by dividing the current appropriate monthly rate by 176 hours. No payment will be made under any circumstances for repair costs, freight and transportation charges, fuel, lubricants, insurance, any other costs and expenses, or overhead and profit. Payment for such equipment made idle by delays attributable to the Government will be based on one-half the derived hourly rate under this subsection.
