Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.
RECOVERY OF ADDITIONAL COSTS If the imposition of or any change in any law, rule, regulation or guideline, or the interpretation or application of any thereof by any court or administrative or governmental authority (including any request or policy not having the force of law) shall impose, modify or make applicable any taxes (except U.S. federal, state or local income or franchise taxes imposed on Lender), reserve requirements, capital adequacy requirements or other obligations which would (a) increase the cost to Lender for extending or maintaining the credit facilities to which this Agreement relates, (b) reduce the amounts payable to Lender under this Agreement or the Related Documents, or (c) reduce the rate of return on Lender's capital as a consequence of Lender's obligations with respect to the credit facilities to which this Agreement relates, then Borrower agrees to pay Lender such additional amounts as will compensate Lender therefor, within five (5) days after Lender's written demand for such payment, which demand shall be accompanied by an explanation of such imposition or charge and a calculation in reasonable detail of the additional amounts payable by Borrower, which explanation and calculations shall be conclusive in the absence of manifest error.
Cost Allocation Cost allocation of Generator Interconnection Related Upgrades shall be in accordance with Schedule 11 of Section II of the Tariff.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Cost Reimbursement This payment method is based on an approved budget and submission of a request for reimbursement of expenses Xxxxxxx has incurred at the time of the request;
CLOSING COSTS AND ADJUSTMENTS All adjustments are made as of settlement date.
Leasing Costs The Sellers shall be responsible for all Leasing Costs that are payable by reason of (i) the execution of an “Existing Lease” (i.e., a Lease existing as of the date of this Agreement) prior to the date of this Agreement, (ii) the renewal, extension, expansion of, or the exercise of any other option under, an Existing Lease, prior to the date of this Agreement, and (iii) amendments of an Existing Lease entered into prior to the date of this Agreement. If the Closing occurs, the Buyer shall be responsible for all Leasing Costs (including commissions to the Sellers’ in-house leasing agents that are customary arms-length terms that would otherwise be negotiated with a third-party leasing agent) that become due and payable as a result of (1) any New Leases, (2) amendments entered into during the Interim Period in accordance with this Agreement to renew, extend, expand or otherwise amend Existing Leases or New Leases, or (3) any renewals, extensions or expansions of, or the exercise of any other option under, Existing Leases or New Leases exercised by tenants during the Interim Period or on or after the Closing Date; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. In addition, the Buyer shall assume the economic effect of any “free rent” or other concessions pertaining to the period from and after the Closing; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. If, as of the Closing Date, the Sellers shall have paid any Leasing Costs for which the Buyer is responsible pursuant to the foregoing provisions, the Buyer shall reimburse the Sellers therefor at Closing; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. The Sellers shall pay (or cause to be paid), prior to Closing, or credit the Buyer at Closing (to the extent unpaid) all Leasing Costs for which the Sellers are responsible pursuant to the foregoing provisions, and (subject to the reimbursement obligations set forth above), the Sellers shall pay (or cause to be paid) when due all Leasing Costs payable after the date of this Agreement and prior to Closing. Notwithstanding anything to the contrary, (a) the Buyer shall receive a credit at Closing for any unfunded contractual Leasing Costs and (b) the Sellers shall be responsible (and the Buyer shall not be responsible) for any leasing commissions or brokerage fees which become due and payable after the Closing pursuant to any leasing or brokerage agreement relating to the Properties, including the Leasing and Brokerage Agreements, except as specifically set forth in Section 3.3(g)(ii). In addition to the foregoing, at Closing, the Buyer shall be responsible (and shall reimburse the Sellers at Closing) for the leasing commissions, tenant improvement costs and concessions for the Leases and the amounts set forth on Schedule 3.3(g)(ii) attached hereto. For purposes hereof, the term “Interim Period” shall mean the period from the date of this Agreement until the Closing Date. On the Closing Date, the Sellers shall deliver to the Buyer all Lease Termination Payments received by or on behalf of the Sellers from and after the date hereof, except, however, the Buyer acknowledges approval of the Leases referenced on Schedule 3.3(g)(ii).
Additional Costs Capital Adequacy (a) If any new law, rule or regulation, or any change after the date hereof in the interpretation or administration of any Applicable Law, rule or regulation by any governmental authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by any Bank or its Applicable Lending Office with any request or directive (whether or not having the force of law) of any such authority, central bank or comparable agency in connection therewith issued, promulgated or enacted after the date hereof shall:
(i) subject any Bank (or its Applicable Lending Office) to any Tax with respect to its Loans, its Note or its Commitment, in each case with respect to any Borrower, or shall change the basis of taxation of payments to any Bank (or its Applicable Lending Office) by such Borrower of the principal of or interest on its Loans or any other amounts due under this Agreement or its Commitment, in each case except for any (A) Covered Tax, or (B) Tax described in clauses (a)(2), (b), (c), or (d) of the definition of Excluded Taxes; or
(ii) impose, modify or deem applicable any reserve (including, without limitation, any such requirement imposed by the Board of Governors of the Federal Reserve System), special deposit, insurance assessment or similar requirement against assets of, deposits with or for the account of, or credit extended by, any Bank (or its Applicable Lending Office) or shall impose on any Bank (or its Applicable Lending Office) any other condition affecting its Loans, its Note or its Commitment, in each case with respect to such Borrower; or
(iii) impose on any Bank any other conditions or requirements with respect to this Agreement, the other Loan Documents, the Loans or such Bank’s Commitment, in each case with respect to such Borrower; and the result of any of the foregoing is to increase the cost to such Bank (or its Applicable Lending Office) of making, funding, issuing, renewing, extending or maintaining any Loan to such Borrower or such Bank’s Commitment in favor of such Borrower, or to reduce the amount of any sum received or receivable by such Bank (or its Applicable Lending Office) from such Borrower under this Agreement or under its Note with respect thereto, by an amount deemed by such Bank to be material, then, promptly upon demand by such Bank (and in any event within thirty (30) days after demand by such Bank) and delivery to such Borrower of the certificate required by clause (c) of this Section (with a copy to the Agent), such Borrower shall pay to such Bank the additional amount or amounts as will compensate such Bank for such increased cost or reduction.
(b) If any Bank shall determine that any change after the date hereof in any existing Applicable Law, rule or regulation or any new law, rule or regulation regarding liquidity or capital adequacy, or any change therein, or any change after the date hereof in the interpretation or administration thereof by any governmental authority, central bank or comparable agency charged with the interpretation or administration thereof, or any new request or directive of general applicability regarding liquidity or capital adequacy (whether or not having the force of law) of any such authority, central bank or comparable agency issued, promulgated or enacted after the date hereof, has or would have the effect of reducing the rate of return on capital of such Bank (or its parent corporation) as a consequence of such Bank’s Loans to a Borrower or obligations to such Borrower hereunder to a level below that which such Bank (or its parent corporation) could have achieved but for such law, change, request or directive (taking into consideration its policies with respect to liquidity and capital adequacy) by an amount deemed by such Bank to be material, then from time to time, promptly upon demand by such Bank (with a copy to the Agent) (and in any event within thirty (30) days after demand by such Bank) such Borrower shall pay to such Bank such additional amount or amounts as will compensate such Bank (or its parent corporation) for such reduction.
(c) Each Bank will promptly notify each Borrower and the Agent of any event of which it has knowledge, occurring after the date hereof, which will entitle such Bank to compensation from such Borrower pursuant to this Section and, upon the written request of the Borrowers, will designate a different Applicable Lending Office if such designation will avoid the need for, or reduce the amount of, such compensation and will not, in the judgment of such Bank, be otherwise disadvantageous to such Bank. A certificate of any Bank claiming compensation under this Section and setting forth in reasonable detail the additional amount or amounts to be paid to it hereunder and the calculations used in determining such additional amount or amounts shall be conclusive in the absence of manifest error. In determining such amount, such Bank may use any reasonable averaging and attribution methods.
(d) Failure or delay on the part of any Bank to demand compensation pursuant to this Section shall not constitute a waiver of such Bank’s right to demand such compensation; provided that the Borrowers shall not be required to compensate a Bank pursuant to this Section for any increased costs or reductions incurred more than nine months prior to the date that such Bank notifies the Borrowers of the change giving rise to such increased costs or reductions and of such Bank’s intention to claim compensation therefor; provided further that, if the change giving rise to such increased costs or reductions is retroactive, then the nine month period referred to above shall be extended to include the period of retroactive effect thereof.
