Litigation and Unilateral Commencement of Arbitration Notwithstanding the foregoing provisions of this Article VII, (a) a Party may seek preliminary provisional or injunctive judicial relief with respect to a Dispute without first complying with the procedures set forth in Section 7.1, Section 7.2 and Section 7.3 if such action is reasonably necessary to avoid irreparable damage and (b) either Party may initiate arbitration before the expiration of the periods specified in Section 7.2 and Section 7.3 if (i) such Party has submitted a Mediation Request or Arbitration Request, as applicable, and the other party has failed, within the applicable periods set forth in Section 7.3, to agree upon a date for the first mediation session to take place within thirty (30) days after the appointment of such mediator or such longer period as the Parties may agree to in writing or (ii) such Party has failed to comply with Section 7.3 in good faith with respect to commencement and engagement in arbitration. In such event, the other Party may commence and prosecute such arbitration unilaterally in accordance with the CPR Arbitration Procedure.
Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.
Right of Claimant to Bring Suit If a written claim received by the Company from or on behalf of an indemnified party under this Article VIII is not paid in full by the Company within 90 days after such receipt, the claimant may at any time thereafter bring suit against the Company to recover the unpaid amount of the claim and, if successful in whole or in part, the claimant shall be entitled to be paid also the expense of prosecuting such claim. It shall be a defense to any such action (other than an action brought to enforce a claim for expenses incurred in defending any proceeding in advance of its final disposition where the required undertaking, if any is required, has been tendered to the Company) that the claimant has not met the standards of conduct which make it permissible under the DGCL for the Company to indemnify the claimant for the amount claimed, but the burden of proving such defense shall be on the Company. Neither the failure of the Company (including the Board, independent legal counsel, or the Member) to have made a determination prior to the commencement of such action that indemnification of the claimant is proper in the circumstances because he or she has met the applicable standard of conduct set forth in the DGCL, nor an actual determination by the Company (including the Board, independent legal counsel, or the Member) that the claimant has not met such applicable standard of conduct, shall be a defense to the action or create a presumption that the claimant has not met the applicable standard of conduct.
Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.
Tax Appeals Purchaser acknowledges that certain of the Sellers, as identified on the Seller Information Schedule (the “Tax Appeal Sellers”) have filed appeals (each, an “Appeal”) with respect to real estate ad valorem or other similar property taxes applicable to the Tax Appeal Properties (the “Property Taxes”).
Notice of Certain Proposed Actions Having Environmental Impact Prompt written notice describing in reasonable detail (A) any proposed acquisition of stock, assets, or property by such Principal Company or any of its Subsidiaries that could reasonably be expected to (1) expose such Principal Company or any of its Subsidiaries to, or result in, Environmental Claims that could reasonably be expected to result in, individually or in the aggregate, a Material Adverse Effect or (2) affect the ability of such Principal Company or any of its Subsidiaries to maintain in full force and effect all material Governmental Authorizations required under any Environmental Laws for their respective operations and (B) any proposed action to be taken by such Principal Company or any of its Subsidiaries to modify current operations in a manner that could reasonably be expected to subject such Principal Company or any of its Subsidiaries to any additional obligations or requirements under any Environmental Laws that could reasonably be expected to result in, individually or in the aggregate, a Material Adverse Effect.
Waiver of Civil Code Section 1542 (a) Executive understands and agrees that the release provided herein extends to all Claims released above whether known or unknown, suspected or unsuspected, which may be released as a matter of law. Executive expressly waives and relinquishes any and all rights he/she may have under California Civil Code section 1542, which provides as follows: “A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS WHICH THE CREDITOR DOES NOT KNOW OR SUSPECT TO EXIST IN HIS OR HER FAVOR AT THE TIME OF EXECUTING THE RELEASE, WHICH IF KNOWN BY HIM OR HER MUST HAVE MATERIALLY AFFECTED HIS OR HER SETTLEMENT WITH THE DEBTOR.”
Notice of Litigation Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any Proceedings or threatened Proceedings concerning any Serviced Appointment, in each case, excluding Proceedings in servicer-managed mortgage-level litigation with respect to residential mortgage-backed securities transactions. Notices delivered pursuant to this Section 5.4 will be delivered to the notice recipient designated on Annex B.
