Notice of Discipline All notices of disciplinary action shall include a statement of the reasons therefor and a statement advising the employee that the action is subject to Article 20,
NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Submission of Formal Disputes a. A Formal Dispute must be filed in writing with the Director of Procurement Services by mail or email, using the following contact information: Email: xxxxxxxx.xxxxxxxx@xxx.xx.xxx
b. The Formal Dispute must include:
i. Name, address, e-mail address and telephone numbers of the filer.
ii. Solicitation or Contract number.
iii. Detailed statement of the legal and factual grounds for the Formal Dispute, including a description of resulting prejudice to the filer.
iv. Copies of relevant documents.
v. Request for a ruling by the agency.
vi. Statement as to the form of relief requested.
vii. All information establishing that the filer is an Interested Party for the purpose of filing a Formal Dispute.
viii. All information establishing the timeliness of the Formal Dispute.
NOTICE OF FORMAL PROCEEDINGS The Trust, MFS, and the Company agree that each such party shall promptly notify the other parties to this Agreement, in writing, of the institution of any formal proceedings brought against such party or its designees by the NASD, the SEC, or any insurance department or any other regulatory body regarding such party's duties under this Agreement or related to the sale of the Policies, the operation of the Accounts, or the purchase of the Shares.
Contract Termination; Debarment A breach of the contract clauses in paragraph 1 through 10 of this section may be grounds for termination of the contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12.
Notice of Force Majeure Event 14.2.1. As soon as practicable and in any case within 3 days of the date of occurrence of a Force Majeure Event or the date of knowledge thereof, the Party which is rendered wholly or partially unable to perform any of its obligations under this Agreement because of a Force Majeure Event (the “Affected Party”) shall notify the other party of the same, setting out, inter alia, the following in reasonable detail:
a) The nature and extent of the Force Majeure Event ;
b) The estimated period for which the Force Majeure Event is expected to last;
c) The nature of and the extent to which, performance of any of its obligations under this Agreement is affected by the Force Majeure Event;
d) The measures which the Affected Party has taken or proposes to take to alleviate/mitigate the impact of the Force Majeure Event and to resume performance of such of its obligations affected thereby; and
e) Any other relevant information concerning the Force Majeure Event, and /or the rights and obligations of the Parties under this Agreement.
Notice of Layoff The Employer shall notify all employees who are to be laid off, fourteen (14) calendar days prior to the effective date of the layoff or shall award pay in lieu thereof.
Notice of Force Majeure If performance is delayed as a result of Force Majeure, the affected party shall provide prompt Notice to the other party and shall be excused from default or delay in performance while such circumstances prevail so long as such party continues to use commercially reasonable efforts to recommence performance as soon as possible.
Notice of Arbitration If a Person asserts that there exists a Dispute, then such Person (the “Disputing Person”) will give each other Person involved in such Dispute a written notice setting forth the nature of the asserted Dispute. If all such Persons do not resolve any such asserted Dispute prior to the 10th business day after such notice is given, then any of them may commence arbitration pursuant to this Paragraph 19 by giving each other Person involved in such Dispute a written notice to that effect (an “Arbitration Notice”), setting forth any matters which are required to be set forth therein in accordance with the AAA Rules.
