Event of Force Majeure means one of the following events:
Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;
Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.
Force Majeure Period has the meaning specified in Section 13.1.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and
Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);
Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;
Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.
Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.
Notice in Writing or written notice shall mean a notice in writing, type or printed characters sent (unless delivered personally or otherwise provided to have been received) by registered post to the last known private or business address or registered office of the addressee and shall be deemed to have been received when in the ordinary course of post it would have been delivered.
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Rectification Notice means a notice in writing that identifies a defect in a work and requires rectification of the defect within a specified period of time.
Force Majeure Failure has the meaning set forth in Section 8.1(d).
Use of force means: (A) Use of a dangerous instrument; or (B) use of actual physical force or violence or superior physical strength against the victim.
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Arbitration Notice has the meaning set forth in Section 9.13.
Deadly force means any use of force that creates a substantial risk of causing death or serious bodily injury, including, but not limited to, the discharge of a firearm.
Mediation Notice is defined in Section 6.2(b).
Dispatch Notice means a notice delivered by CAISO to Owner’s Scheduling Coordinator on a daily, hourly or real-time basis requesting dispatch of one or more Unit(s) to provide Energy or Ancillary Services under this Agreement. Dispatch Notices include: (a) Day-Ahead Schedules and Real-Time Dispatches where the RMR Unit or Units are flagged as RMR Dispatches as a result of the Market-Power Mitigation and Reliability Requirements Determination processes pursuant to the CAISO Tariff, (b) Manual RMR Dispatch Notices, (c) notices deemed to have been given by CAISO for the Energy actually Delivered by a Unit that starts or increases Energy output as a result of a “system emergency” as defined in the CAISO Tariff whether the start or increase occurs automatically (for Units specified in Section 2 of Schedule A as having the ability to Start-up or ramp automatically) or pursuant to a standing written order of the CAISO, and (d) Test Dispatch Notices given by CAISO under Section 4.9 other than Test Dispatch Notices issued at Owner’s request to test Availability or heat input of the Unit.
Notice of Dispute has the meaning provided in Section 2.1(f)(iii) of this Commercial Shared-Loss Agreement.
complaining Party means any Party that requests the establishment of an arbitration panel under Article 3.5 (Initiation of the Arbitration Procedure);
Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:
CAFA Notice refers to the notice requirements imposed by 28 U.S.C. § 1715(b).