Other Architects and Engineers Sample Clauses

Other Architects and Engineers. Except in respect of the Design Architect (which shall be approved in accordance with Section 6.1(d)(i) hereof), the Production Architect and each other architect and engineer proposed to be engaged in respect to any Construction Work (other than Interior Construction Work or demolition work (other than the Demolition Work)) (A) governed by any element of the DUO, (B) affecting a Structural Component (other than by having a Nonadverse Structural Effect), or (C) of a value of greater than $1,000,000 (which amount shall be Adjusted for Inflation from the Substantial Completion Date), shall be approved by Landlord: (1) in respect of any Construction Work subject to clause (A) of this Section 6.1(d)(ii), in Landlord’s sole discretion; and (2) in respect of Construction Work subject only to clause (B) or (C) of this Section 6.1(d)(ii), in Landlord’s approval not to be unreasonably withheld. Each such Architect shall have substantial experience in construction projects that are comparable in scope to such architect’s intended work at the Project and shall not be a Prohibited Person. Each such Engineer shall (x) be of recognized standing among its peers, (y) have at least ten (10) years experience in providing engineering services in respect of highrise buildings in urban centers and (z) not be a Prohibited Person. If Landlord fails to approve or reject any architect nominated by Tenant to be an Architect (other than the Design Architect), or engineer nominated by Tenant to be an Engineer, as the case may be, within sixteen (16) Business Days after the written submission to Landlord of such architect’s name and other information (including adequate portfolio information) sufficiently detailed to permit Landlord to make a reasoned judgment of the appropriateness of the proposed architect or engineer, as the case may be, for the 00xx Xxxxxx Project, or Landlord fails to make reasonable requests for additional information related thereto within such time period and thereafter to approve or reject such architect or engineers, as the case may be within eleven (11) Business Days after written submission of such additional information as Landlord shall have reasonably requested, Tenant shall have the right to give Landlord a reminder notice, which reminder notice shall contain the following caption in bold and capitalized type: If Landlord fails to approve or reject the proposed architect or engineers, as the case may be, within five (5) Business Days after its receipt ...
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs

Related to Other Architects and Engineers

  • Architect Engineer shall provide assistance to Owner through the commissioning consultant/agent for the purpose of advising and counseling Owner’s personnel in the usage, operation and maintenance of the building mechanical, electrical, and plumbing systems.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • The Architect ENGINEER shall prepare for the State a revised accounting of how the Project responds to LEED criteria.

  • Geotechnical Engineer « »« » « » « » « » « »

  • Professional Engineering and Architect’s Services Professional Engineering and Architect’s Services are not permitted to be provided under this Agreement. Texas statutes prohibit the procurement of Professional Engineering and Architect’s Services through a cooperative agreement.

  • Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.

  • Design Professional The architect or engineer or architectural or engineering firm selected by Owner (i) for the design and preparation of Contract Documents governing the construction of a Project, or (ii) for construction contract administration under the Contract Documents, or (iii) for both, all such services and the scope thereof to be set forth in the Design Professional Contract. The Design Professional is not an employee of the Owner but is engaged or retained by it for the purpose of performing design and construction administration services for the project. The term “Design Professional” includes architects, engineers, surveyors, designers, and other consultants retained by the Design Professional.

  • ENGINEER The individual or entity named as such in this Agreement.

  • Contractors All LAUSD Contractors and their Representatives are expected to conduct any and all business affiliated with LAUSD in an ethical and responsible manner that fosters integrity and public confidence. A “Contractor” is any individual, organization, corporation, sole proprietorship, partnership, nonprofit, joint venture, association, or any combination thereof that is pursuing or conducting business with and/or on behalf of LAUSD, including, without limitation, consultants, suppliers, manufacturers, and any other vendors, bidders or proposers. A Contractor’s “Representative” is also broadly defined to include any subcontractors, employees, agents, or anyone else who acts on a Contractor’s behalf.

  • Contractors and Subcontractors Drug-Free Workplace Act of 1988 1) Publish and give a policy statement to all covered employees informing them that the unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited in the covered workplace and specifying the actions that will be taken against employees who violate the policy. 2) Establish a drug-free awareness program to make employees aware of a) the dangers of drug abuse in the workplace; b) the policy of maintaining a drug-free workplace; c) any available drug counseling, rehabilitation, and employee assistance programs; and d) the penalties that may be imposed upon employees for drug abuse violations. 3) Notify employees that as a condition of employment on a federal contract or grant, the employee must a) abide by the terms of the policy statement; and b) notify the employer, within five (5) calendar days, if he or she is convicted of a criminal drug violation in the workplace. 4) Notify the contracting or granting agency within ten (10) days after receiving notice that a covered employee has been convicted of a criminal drug violation in the workplace. 5) Impose a penalty on or require satisfactory participation in a drug abuse assistance or rehabilitation program by any employee who is convicted of a reportable workplace drug conviction. 6) Make an ongoing, good faith effort to maintain a drug-free workplace by meeting the requirements of the act.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!