Other Management Fees for Construction Management Services. The Owner agrees to pay Contractor a management fee as specified in the appropriate Property Amendment.
Other Management Fees for Construction Management Services Sample Clauses
Related to Other Management Fees for Construction Management Services
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Asset Management Services (i) Real Estate and Related Services: (a) Investigate, select and, on behalf of the Company, engage and conduct business with (including enter contracts with) such Persons as the Advisor deems necessary to the proper performance of its obligations as set forth in this Agreement, including but not limited to consultants, accountants, lenders, technical advisors, attorneys, brokers, underwriters, corporate fiduciaries, escrow agents, depositaries, custodians, agents for collection, insurers, insurance agents, developers, construction companies, Property Managers and any and all Persons acting in any other capacity deemed by the Advisor necessary or desirable for the performance of any of the foregoing services; (b) Negotiate and service the Company’s debt facilities and other financings; (c) Monitor applicable markets and obtain reports (which may be prepared by the Advisor or its Affiliates) where appropriate, concerning the value of investments of the Company; (d) Monitor and evaluate the performance of each asset of the Company and the Company’s overall portfolio of assets, provide daily management services to the Company and perform and supervise the various management and operational functions related to the Company’s investments; (e) Formulate and oversee the implementation of strategies for the administration, promotion, management, operation, maintenance, improvement, financing and refinancing, marketing, leasing and disposition of Properties, Loans and other Permitted Investments on an overall portfolio basis; (f) Consult with the Company’s officers and the Board and assist the Board in the formulation and implementation of the Company’s financial policies, and, as necessary, furnish the Board with advice and recommendations with respect to the making of investments consistent with the investment objectives and policies of the Company and in connection with any borrowings proposed to be undertaken by the Company; (g) Oversee the performance by the Property Managers of their duties, including collection and proper deposits of rental payments and payment of Property expenses and maintenance; (h) Conduct periodic on-site property visits to some or all (as the Advisor deems reasonably necessary) of the Properties to inspect the physical condition of the Properties and to evaluate the performance of the Property Managers; (i) Review, analyze and comment upon the operating budgets, capital budgets and leasing plans prepared and submitted by each Property Manager and aggregate these property budgets into the Company’s overall budget; (j) Coordinate and manage relationships between the Company and any co-venturers or partners; and (k) Consult with the Company’s officers and the Board and provide assistance with the evaluation and approval of potential asset dispositions, sales and refinancings. (ii) Accounting and Other Administrative Services: (a) Provide the day-to-day management of the Company and perform and supervise the various administrative functions reasonably necessary for the management of the Company; (b) From time to time, or at any time reasonably requested by the Board, make reports to the Board on the Advisor’s performance of services to the Company under this Agreement; (c) Make reports to the Conflicts Committee each quarter of the investments that have been made by other programs sponsored by the Advisor or any of its Affiliates, including KBS Realty Advisors LLC, as well as any investments that have been made by the Advisor or any of its Affiliates directly; (d) Provide or arrange for any administrative services and items, legal and other services, office space, office furnishings, personnel and other overhead items necessary and incidental to the Company’s business and operations; (e) Provide financial and operational planning services; (f) Maintain accounting and other record-keeping functions at the Company and investment levels, including information concerning the activities of the Company as shall be required to prepare and to file all periodic financial reports, tax returns and any other information required to be filed with the SEC, the Internal Revenue Service and any other regulatory agency; (g) Maintain and preserve all appropriate books and records of the Company; (h) Provide tax and compliance services and coordinate with appropriate third parties, including the Company’s independent auditors and other consultants, on related tax matters; (i) Provide the Company with all necessary cash management services; (j) Manage and coordinate with the transfer agent the dividend process and payments to Stockholders; (k) Consult with the Company’s officers and the Board and assist the Board in evaluating and obtaining adequate insurance coverage based upon risk management determinations; (l) Provide the Company’s officers and the Board with timely updates related to the overall regulatory environment affecting the Company, as well as managing compliance with such matters, including but not limited to compliance with the Xxxxxxxx-Xxxxx Act of 2002; (m) Consult with the Company’s officers and the Board relating to the corporate governance structure and appropriate policies and procedures related thereto; (n) Perform all reporting, record keeping, internal controls and similar matters in a manner to allow the Company to comply with applicable law, including federal and state securities laws and the Xxxxxxxx-Xxxxx Act of 2002; (o) Notify the Board of all proposed material transactions before they are completed; and (p) Do all things necessary to assure its ability to render the services described in this Agreement.
Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout
Management Services The Adviser shall perform (or arrange for the performance by its affiliates of) the management and administrative services necessary for the operation of the Fund. The Adviser shall, subject to the supervision of the Board of Trustees, perform various services for the Portfolio, including but not limited to: (i) providing the Portfolio with office space, equipment and facilities (which may be its own) for maintaining its organization; (ii) on behalf of the Portfolio, supervising relations with, and monitoring the performance of, custodians, depositories, transfer and pricing agents, accountants, attorneys, underwriters, brokers and dealers, insurers and other persons in any capacity deemed to be necessary or desirable; (iii) preparing all general shareholder communications, including shareholder reports; (iv) conducting shareholder relations; (v) maintaining the Fund's existence and its records; (vi) during such times as shares are publicly offered, maintaining the registration and qualification of the Portfolio's shares under federal and state law; and (vii) investigating the development of and developing and implementing, if appropriate, management and shareholder services designed to enhance the value or convenience of the Portfolio as an investment vehicle. The Adviser shall also furnish such reports, evaluations, information or analyses to the Fund as the Fund's Board of Trustees may request from time to time or as the Adviser may deem to be desirable. The Adviser shall make recommendations to the Fund's Board of Trustees with respect to Fund policies, and shall carry out such policies as are adopted by the Trustees. The Adviser shall, subject to review by the Board of Trustees, furnish such other services as the Adviser shall from time to time determine to be necessary or useful to perform its obligations under this Contract.
Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity 1.1.02 Identify at least one individual to act as the program contact in the following areas: 1. Immunization Program Manager;
