Third Party Technology The Company makes use of third party technology to collect information required for traffic measurement, research, and analytics. Use of third party technology entails data collection. We therefore would like to inform clients the Company enables third parties to place or read cookies located on the browsers of users entering the Company’s domain. Said third parties may also use web beacons to collect information through advertising located on the Company’s web site. Please note that you may change your browser settings to refuse or disable Local Shared Objects and similar technologies; however, by doing so you may be disabling some of the functionality of Company’s services.
Competing Products The provisions of Section 21 are set forth on attached Exhibit H and are incorporated in this Section 21 by this reference.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Third Party Licenses If (a) in the opinion of outside patent counsel to Licensee, Licensee, or any of its Affiliates or Sublicensees, cannot Exploit a Licensed Product in a country in the Territory without infringing one or more Patents that have issued to a Third Party in such country, or (b) as a result of any claim made against a Party, or any of its Affiliates or Sublicensees, alleging that the Exploitation of a Licensed Product infringes or misappropriates any Patent or any other intellectual property right of a Third Party in a country in the Territory, a judgment is entered by a court of competent jurisdiction from which no appeal is taken within the time permitted for appeal, such that Licensee cannot Exploit such Licensed Product in such country without infringing the Patent or other proprietary rights of such Third Party, then, in either case, Licensee shall have the first right, but not the obligation to negotiate and to obtain a license from such Third Party as necessary for the Exploitation of any Licensed Product hereunder in such country; provided, however, that NovaDel shall have the sole right to seek any such license with respect to the Licensed Process and shall use commercially reasonable efforts to obtain such a license in its own name from such Third Party in such country, under which NovaDel shall, to the extent permissible under such license, grant a sublicense to Licensee as necessary for Licensee, and any of its Affiliates and Sublicensees, to Exploit the Licensed Product as provided hereunder in such country. Licensee shall be solely responsible for one hundred percent (100%) of all royalty and other obligations with respect to the Exploitation of the Licensed Product; provided, however, that Licensee shall have the right to credit fifty percent (50%) any royalties paid by Licensee, its Affiliates or Sublicensees under such license with respect to such country against the royalty payments to be paid by Licensee to NovaDel with respect to the sale of the Licensed Product(s) under Section 4.1; provided, however, that no royalty payment when due, regardless of the amount or number of credits available to Licensee in accordance with this Agreement, shall be reduced by more than fifty percent (50%) of the amounts otherwise owed pursuant to Section 4.1 in any calendar quarter. Credits not exhausted in any calendar quarter may be carried into future calendar quarters.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
