PAYMENT TO THE CONTRACTOR IF THE CITY CAUSES DELAY Sample Clauses

PAYMENT TO THE CONTRACTOR IF THE CITY CAUSES DELAY. Should the City be prevented or enjoined from proceeding with Work either before or after the start of construction, by reason or any litigation or reason beyond the control of the City, the Contractor shall not be entitled to make or assert claim for damage by reason of said delay but time for completion of the Work will be extended to such reasonable time as the City may determine will compensate for lost time by such delay with such determination to be set forth in writing. If the City causes a delay for its convenience, payment to the Contractor shall be made in accordance with X.X. x. 30, §39O, including all current amendments, generally as follows: The City may order the Contractor in writing to suspend, delay, or interrupt all or any part of the Work for such period of time as it may determine to be appropriate for the convenience of the City; provided however, that if there is a suspension, delay or interruption for fifteen (15) days or more or due to a failure of the City to act within the time specified in this contract, the City shall make an adjustment in the Contract Price for any increase in the cost of performance of this contract but shall not include any profit to the Contractor on such increase; and provided further, that the City shall not make any adjustment in the Contract Price under this provision for any suspension, delay, interruption or failure to act to the extent that such is due to any cause for which this contract provides for an equitable adjustment of the Contract Price under any other contract provisions. The Contractor must submit the amount of a claim under provision “a” to the City in writing as soon as practicable after the end of the suspension, delay, interruption or failure to act and, in any event, not later than the date of final payment under this contract and, except for costs due to a suspension order, the City shall not approve any costs in the claim incurred more than twenty days before the Contractor notified the City in writing of the act or failure to act involved in the claim. In the event a suspension, delay, interruption or failure to act of the City increases the cost of performance to any Subcontractor, that subcontractor shall have the same rights against the Contractor for payment for an increase in the cost of his performance as provisions “a” and “b” give the general contractor against the awarding authority, but nothing in provisions “a” and “b” shall in any way change, modify or alter any other r...
Sample 1
AutoNDA by SimpleDocs

Related to PAYMENT TO THE CONTRACTOR IF THE CITY CAUSES DELAY

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.

  • Termination for Cause If Vendor fails to materially perform pursuant to the terms of this Agreement, TIPS shall provide written notice to Vendor specifying the default. If Vendor does not cure such default within thirty (30) days, TIPS may terminate this Agreement, in whole or in part, for cause. If TIPS terminates this Agreement for cause, and it is later determined that the termination for cause was wrongful, the termination shall automatically be converted to and treated as a termination for convenience.

  • Termination This Agreement may be terminated at any time prior to the Closing:

  • ATTORNEYS’ FEES In the event of any dispute between the parties concerning the terms and provisions of this Warrant, the party prevailing in such dispute shall be entitled to collect from the other party all costs incurred in such dispute, including reasonable attorneys’ fees.

  • Term and Termination In any case, if not sooner terminated, this Agreement shall expire at the close of business on the effective date that the Offering is terminated. This Agreement may be terminated by either party (a) immediately upon notice to the other party in the event that the other party shall have materially failed to comply with any material provision of this Agreement or if any of the representations, warranties, covenants or agreements of such party contained herein shall not have been materially complied with and such failure to comply is not cured within ten (10) days after the date of such occurrence or (b) on 60 days’ written notice. In any event, this Agreement shall be deemed suspended during any period for which the Dealer Manager’s license or registration to act as a broker dealer shall be revoked or suspended by any federal, self-regulatory or state agency. In addition, the Dealer Manager, upon the expiration or termination of this Agreement, shall (a) promptly deposit any and all funds in its possession which were received from investors for the sale of Shares into the appropriate escrow account or, if the Minimum Offering has been reached, into such other account as the Company may designate; and (b) promptly deliver to the Company all records and documents in its possession which relate to the Offering which are not designated as dealer copies. The Dealer Manager, at its sole expense, may make and retain copies of all such records and documents required to be retained by the Dealer Manager pursuant to (i) Federal and state securities laws and the rules and regulations thereunder, (ii) the applicable rules of FINRA and (iii) the NASAA REIT Guidelines, but shall keep all such information confidential; provided, that, nothing contained in this Agreement shall prevent the Dealer Manager from disclosing any such information to any regulatory authority asserting jurisdiction over the Dealer Manager. The Dealer Manager shall use its reasonable best efforts to cooperate with the Company to accomplish any orderly transfer of management of the Offering to a party designated by the Company. Upon expiration or termination of this Agreement, the Company shall pay to the Dealer Manager all earned but unpaid compensation and reimbursement for all incurred, accountable compensation to which the Dealer Manager is or becomes entitled under Section 5 of this Agreement, including but not limited to any Distribution Fees, pursuant to the requirements of that Section 5 at such times as such amounts become payable pursuant to the terms of such Section 5 without acceleration; provided, however, that if the Minimum Offering is not reached prior to such expiration or termination, the Company shall not pay any such compensation and reimbursements to the Dealer Manager.

  • Limitation of Liability No provision hereof, in the absence of any affirmative action by the Holder to exercise this Warrant to purchase Warrant Shares, and no enumeration herein of the rights or privileges of the Holder, shall give rise to any liability of the Holder for the purchase price of any Common Stock or as a stockholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.

  • Insurance The Company and the Subsidiaries are insured by insurers of recognized financial responsibility against such losses and risks and in such amounts as are prudent and customary in the businesses in which the Company and the Subsidiaries are engaged, including, but not limited to, directors and officers insurance coverage. Neither the Company nor any Subsidiary has any reason to believe that it will not be able to renew its existing insurance coverage as and when such coverage expires or to obtain similar coverage from similar insurers as may be necessary to continue its business without a significant increase in cost.

  • Indemnification In the event any Registrable Securities are included in a Registration Statement under this Agreement:

  • Dispute Resolution All or any disputes arising out or touching upon or in relation to the terms and conditions of this Agreement, including the interpretation and validity of the terms thereof and the respective rights and obligations of the Parties, shall be settled amicably by mutual discussion, failing which the same shall be settled through the adjudicating officer appointed under the Act.

  • Independent Contractor The Contractor and its employees, agents, representatives, and subcontractors are independent contractors and not employees or agents of the State of Florida and are not entitled to State of Florida benefits. The Department and Customer will not be bound by any acts or conduct of the Contractor or its employees, agents, representatives, or subcontractors. The Contractor agrees to include this provision in all its subcontracts under the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!