Performance of Scope of Changes Sample Clauses

Performance of Scope of Changes. If Concessionaire executes and delivers to Contractor a Work Order, or if Concessionaire and Contractor agree to a Scope Change Order, Contractor promptly shall perform the TTMS Work described in the Work Order or Scope Change Order. With respect to TTMS Work performed pursuant to a Work Order, Contractor shall deliver to Concessionaire, within thirty (30) days after completion, invoices, statements, payroll data and other evidence of the actual cost of the TTMS Work attributable to the Work Order that Concessionaire may reasonably require.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Performance of Scope of Changes. If the Concessionaire executes and delivers to the DB Contractor a Work Order, or if the Concessionaire and the DB Contractor agree to a Scope Change Order, the DB Contractor promptly shall perform the DB Work described in the Work Order or Scope Change Order. The Concessionaire shall not be responsible for premium time work unless (i) the Concessionaire has expressly directed the performance of premium time work, (ii) the need for such premium time work was not caused by the DB Contractor, and (iii) such premium time work was not contemplated by the DB Contractor’s original work plan. With respect to DB Work performed pursuant to a Work Order, the DB Contractor shall deliver to the Concessionaire, within 20 Days after completion, invoices, statements, payroll data and other evidence of the actual cost of the DB Work attributable to the Work Order that the Concessionaire may reasonably require. Promptly following (i) completion of the Scope Change required under a Work Order, (ii) agreement by the Concessionaire and the DB Contractor as to the adjustments to the Contract Sum, the Payment and Values Schedule, the Scheduled Substantial Completion Dates or the Long Stop Date which should be permitted as a result of such Work Order, and (iii) receipt by the Concessionaire of all required invoices, statements, payroll data and other evidence of the actual cost of the DB Work performed pursuant to such Work Order, the Concessionaire shall issue a Scope Change Order adjusting one or more of the Contract Sum, the Payment and Values Schedule, the Scheduled Substantial Completion Dates and the Long Stop Date as so agreed by the Concessionaire and the DB Contractor. If the Scope Change under a Work Order is performed over a period of more than one month, the DB Contractor may request, and shall be entitled to, payments for the Scope Change performed during each month in the same manner as payments requested for other DB Work. Agreement on any Scope Change Order shall constitute a final settlement on all items covered therein, subject to performance thereof and payment therefor pursuant to this Agreement.
Sample 1

Related to Performance of Scope of Changes

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .

  • Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.

  • General Scope of Services Contractor promises and agrees to furnish all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply professional services, as more particularly described in Exhibit B (Statement of Work and Misc. Documents) attached hereto and incorporated herein by reference (collectively “Services”). All Services shall be subject to, and performed in accordance with, this Contract, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

  • SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.

  • Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in: a. its certificate of incorporation or other organizational document; b. more than a controlling interest in the ownership of the Contractor; or c. the individual(s) in charge of the Performance. This change shall not relieve the Contractor of any responsibility for the accuracy and completeness of the Performance. DAS, after receiving written notice by the Contractor of any such change, may require such agreements, releases and other instruments evidencing, to DAS’s satisfaction, that any individuals retiring or otherwise separating from the Contractor have been compensated in full or that provision has been made for compensation in full, for all work performed under terms of the Contract. The Contractor shall deliver such documents to DAS in accordance with the terms of DAS’s written request. DAS may also require, and the Contractor shall deliver, a financial statement showing that solvency of the Contractor is maintained. The death of any Contractor Party, as applicable, shall not release the Contractor from the obligation to Perform under the Contract; the surviving Contractor Parties, as appropriate, must continue to Perform under the Contract until Performance is fully completed.

  • Performance and Compliance Purchaser shall have performed all of the covenants and complied, in all material respects, with all the provisions required by this Agreement to be performed or complied with by it on or before the Closing.

  • Performance of Reviews The RIRs shall send a request for review to the Operator per email, where they shall specify the areas they request a review for. The Operator must comply with the request by providing the requested information within working days. The review may include an onsite inspection. In this case the RIRs and the Operator must agree on a specific date for the inspection to take place, which may not be later than sixty calendar days from the date of the request.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

  • Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!