Preliminary Plans Tenant shall prepare and submit to Landlord for approval schematics of the Tenant Improvements prepared in conformity with the applicable provisions of this Exhibit F (the “Preliminary Plans”). The Preliminary Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Preliminary Plans whether Landlord approves or objects to the Preliminary Plans and of Landlord’s specific objections to the Preliminary Plans (if any). Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Preliminary Plans, then Tenant shall revise the Preliminary Plans to remedy Landlord’s objections. Tenant shall then resubmit the revised Preliminary Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to any revised Preliminary Plans and Tenant’s correction of the same shall continue as provided above for the original Preliminary Plans until Landlord has approved the Preliminary Plans in writing. The Preliminary Plans that are approved by Landlord without objection shall be referred to as the “Approved Preliminary Plans.”
Final Plans When authorized by the CITY prepare final plans for the PROJECT based upon com- ments as agreed upon as a result of the office check review. Major items of work included in devel- opment of final plans are:
(a) Prepare engineering plans (which shall include construction sequencing and traffic con- trol), supplemental specifications, special provisions and construction cost estimates, or esti- mates of the quantities of work for the PROJECT.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Improvement Plans A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.
Annual Work Plans and Budgets The Recipient shall furnish to the Association as soon as available, but in any case not later than September 1 of each year, the annual work plan and budget for the Project for each subsequent year of Project implementation, of such scope and detail as the Association shall have reasonably requested, except for the annual work plan and budget for the Project for the first year of Project implementation, which shall be furnished no later than one (1) month after the Effective Date.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Preliminary Design Phase 30 percent plans)
A. Proceed with Preliminary Design Phase after the completion of the Conceptual phase which includes: Acceptance by Owner of the Conceptual Report and any other Study and Report Phase deliverables; selection by Owner of a recommended solution; issuance by Owner of any instructions for use of Project Strategies, Technologies, and Techniques, or for inclusion of sustainable features in the design, and Indication by Owner of any specific modifications or changes in the scope, extent, character, or design requirements of the Project desired by Owner.
1. Prepare Preliminary Design Phase documents consisting of final design criteria, preliminary drawings, outline specifications, and written descriptions of the Project.
2. Include on plans, property lines, structure locations, ownership names and contact information.
3. In preparing the Preliminary Design Phase documents, use any specific applicable Project Strategies, Technologies, and Techniques authorized by Owner during or following the Study and Conceptual Phase, and include sustainable features, as appropriate, pursuant to Owner’s instructions.
4. Provide necessary field surveys, topographic and utility mapping for Engineer’s design purposes. Comply with the scope of work and procedure for the identification and mapping of existing utilities as defined by Section A1.03 “Utility Requirements” and Section A1.04 “Survey Services”
5. Visit the Site as needed to prepare the Preliminary Design Phase documents.
6. Advise Owner if additional reports, data, information, or services of the types described are necessary and assist Owner in obtaining such reports, data, information, or services.
7. Continue to assist Owner with Project Strategies, Technologies, and Techniques that Owner has chosen to implement.
8. Based on the information contained in the Preliminary Design Phase documents, prepare a revised opinion of probable Construction Cost, and assist Owner in tabulating the various cost categories which comprise Total Project Costs.
9. Obtain and review Owner’s instructions regarding Owner’s procurement of construction services (including instructions regarding advertisements for bids, instructions to bidders, and requests for proposals, as applicable), Owner’s construction contract practices and requirements, insurance and bonding requirements, electronic transmittals during construction, and other information necessary for the finalization of Owner’s bidding-related documents (or requests for proposals or other construction procurement documents), and Construction Contract Documents. Also obtain and review copies of Owner’s design and construction standards, Owner’s standard forms, general conditions, supplementary conditions, text, and related documents or content for Engineer to include in the draft bidding-related documents (or requests for proposals or other construction procurement documents), and in the draft Construction Contract Documents, when applicable.
10. Development communication plan for project: considering the use of door hangers, letters, public meetings, changeable message boards.
11. Furnish 6 review copies of the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables to Owner by established due date, and review them with Owner. Owner shall submit to Engineer any comments regarding the furnished items.
12. Revise the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables in response to Owner’s comments, as appropriate, and furnish to Owner 6 copies of the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables by the specified due date.
13. Engineer’s services under the Preliminary Design Phase will be considered complete on the date when Engineer has delivered to Owner the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables.
Development Plans Shipper has provided Gatherer with a report attached hereto as Exhibit D (the “Current Development Plan”) describing in detail, as of January 1, 2017, the planned development, drilling, and production activities to take place with respect to Dedicated Production for the applicable Development Period. The information contained in the TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Current Development Plan is broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by the Current Development Plan, on a Quarter-by-Quarter basis, and with respect to the remaining Years covered by the Current Development Plan, on a Year-by-Year basis. The Current Development Plan attached hereto has been approved by the Parties.
(a) From time to time during each Year of the Term, the Parties shall meet to discuss the planned development, drilling, and production activities that Shipper expects to take place with respect to Dedicated Production for the then-applicable Development Period. Shipper and Gatherer shall each make their respective representatives available to participate in such meetings and discussions. No later than August 1 of each such Year, Shipper shall provide (or cause to be provided) to Gatherer a proposed update of the then-currently agreed Development Plan, prepared on the same basis as the Current Development Plan and describing in detail the planned development, drilling, and production activities to take place with respect to Dedicated Production for the then-applicable Development Period (any such update, an “Updated Development Plan” and, together with the Current Development Plan, each, a “Development Plan”). Notwithstanding anything herein to the contrary, in no event shall Gatherer be required to agree to any Updated Development Plan and corresponding updated Gathering System Plan that contains a Committed Build-Out that (i) has a corresponding Target Completion Date that occurs after the end of the Initial Term, and (ii) Gatherer, in its sole discretion, does not wish to approve.
(b) Each proposed Development Plan shall include information as to the following, in each case, broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by such Development Plan, on a Quarter-by-Quarter basis, and, with respect to the remaining Years covered by such Development Plan, on a Year-by-Year basis:
(i) all Xxxxx that, as of the date such Development Plan was delivered, are currently in existence and (A) the production therefrom is being delivered into the Gathering System, or (B) are awaiting connection to the Gathering System;
(ii) the Xxxxx that are expected to be drilled during the time period covered by such Development Plan (each such Well reflected in such Development Plan, a “Planned Well”), and the estimated timing of the drilling of such Planned Xxxxx;
(iii) forward-looking production estimates for the applicable time period covered by such Development Plan for all Shipper Gas (A) that Shipper reasonably and in good faith believes will become owned or Controlled by Shipper during the time period covered by such Development Plan, and/or (B) that will be produced from (I) in the aggregate, all Xxxxx then-existing and (II) in the aggregate, any Planned Xxxxx included in such Development Plan (such collective estimates described in subsections (A) and (B), both with respect to a particular Quarter and an entire Year, the “Dedicated Production Estimates”); TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
(iv) forward-looking estimates for the applicable time period covered by such Development Plan of the aggregate volumes of those Shipper Injected Liquids that Shipper intends to Tender to the Injection Points hereunder to receive the System Services (such estimates, both with respect to a particular Quarter and an entire Year, the “System Liquids Estimates” and, together with the Dedicated Production Estimates, the “System Production Estimates”);
(v) (A) each new receipt point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such receipt point, including those located at the site of a Planned Well, a “Planned Receipt Point”), (B) each Receipt Point at which Shipper expects to Tender Shipper Gas and/or Shipper Injected Liquids reflected in such Development Plan into the Gathering System, and (C) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to Tender at each such Receipt Point and Planned Receipt Point;
(vi) the earliest date on which each Planned Well included in the Development Plan is estimated to be completed and producing, which date shall not be earlier than three Months after the January 1st that is immediately subsequent to the date that the Development Plan that initially reflected such Planned Well was delivered to Gatherer hereunder;
(vii) the anticipated characteristics of the production from the Xxxxx and Planned Xxxxx reflected in such Development Plan (including liquids content and gas and liquids composition) and the projected production volumes and production pressures applicable thereto; provided that Shipper may utilize the existing and historical production information from similarly situated Xxxxx;
(viii) (A) each new delivery point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such delivery point, a “Planned Delivery Point”), (B) each Delivery Point at which Shipper expects Shipper Gas produced from the Xxxxx and Planned Xxxxx reflected in such Development Plan to be redelivered to Shipper, (C) each Delivery Point at which Shipper expects any Drip Liquids allocated to Shipper in accordance with this Agreement and/or Shipper Injected Liquids to be redelivered to Shipper, and (D) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to be redelivered to Shipper at each such Delivery Point and Planned Delivery Point;
(ix) any (A) proposed revision to the then-existing Dedicated Area and/or any then-existing Dedicated Contract and/or (B) any new contract that Shipper proposes to be a Dedicated Contract; and
(x) other information reasonably requested by Gatherer that is relevant to the design, construction, and operation of the Gathering System, including (A) any Subsystem Extension proposed by Shipper, (B) the relevant Receipt Point, Planned Receipt Point, Delivery Point and Planned Delivery Point facilities applicable to such TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Development Plan, and (C) any treating, processing, or liquids handling facilities proposed by Shipper that may be required for any Shipper Gas and/or Shipper Injected Liquids to meet applicable Downstream Facility specifications at the Delivery Points.
