Political Event A Political Event shall mean one or more of the following acts or events by or on account of any Government Instrumentality:
(a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 37 and its effect, in financial terms, exceeds the sum specified in Clause 37.1;
(b) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Concessionaire or of the Contractors;
(c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Concessionaire or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit;
(d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
(e) any event or circumstance of a nature analogous to any of the foregoing.
Political Activity An employee shall not use his or her official authority for the purpose of interfering with or affecting the nomination or election of any candidate for public office. An employee shall not command or solicit in a coercive fashion from any other employee direct or indirect participation in any political activity or enforce or solicit in a coercive fashion contribution for any political party, organization, or candidate. An employee shall retain his or her right to vote and freely express opinions on all political subjects. An employee shall not be prohibited from participation in local community activities or from holding public office in the community in which the employee resides, provided that such activity does not conflict with Section 3.01 of the Rules and Regulations for Personnel Administration (and the Federal Hatch Act to the extent that employees of agencies receiving federal funds are subject thereto).
Non-Political Event A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor;
(e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority;
(f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or
(g) any event or circumstances of a nature analogous to any of the foregoing.
Indirect Political Event An Indirect Political Event shall mean one or more of the following acts or events:
(a) an act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or military action, civil commotion or politically motivated sabotage;
(b) industry-wide or State-wide strikes or industrial action for a continuous period of 24 (twenty four) hours and exceeding an aggregate period of 7 (seven) days in an Accounting Year;
(c) any civil commotion, boycott or political agitation which prevents collection of Fee by the Concessionaire for an aggregate period exceeding 7 (seven) days in an Accounting Year;
(d) any failure or delay of a Contractor to the extent caused by any Indirect Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(e) any Indirect Political Event that causes a Non-Political Event; or
(f) any event or circumstances of a nature analogous to any of the foregoing.
Political Activities Grant funds cannot be used for the following activities:
A. Grantees and their relevant sub-grantees or subcontractors are prohibited from using grant funds directly or indirectly for political purposes, including lobbying, advocating for legislation, campaigning for, endorsing, contributing to, or otherwise supporting political candidates or parties, and voter registration campaigns. Grantees may use private, or non-System Agency money or contributions for political purposes but may not charge to, or be reimbursed from, System Agency contracts or grants for the costs of such activities.
X. Xxxxx-funded employees may not use official authority or influence to achieve any political purpose and grant funds cannot be used for the salary, benefits, or any other compensation of an elected official.
X. Xxxxx funds may not be used to employ, in any capacity, a person who is required by Chapter 305 of the Texas Government Code to register as a lobbyist. Additionally, grant funds cannot be used to pay membership dues to an organization that partially or wholly pays the salary of a person who is required by Chapter 305 of the Texas Government Code to register as a lobbyist.
D. As applicable, Grantee will comply with 31 USC § 1352, relating to the limitation on use of appropriated funds to influence certain Federal contracting and financial transactions.
Political Contributions Neither the Company nor any of its Subsidiaries has, directly or indirectly, at any time (x) made any contributions to any candidate for political office, or failed to disclose fully any such contribution, in violation of law; (y) made any payment to any state, federal or foreign governmental officer or official, or other person charged with similar public or quasi-public duties, other than payments required or allowed by all applicable laws; or (z) violated nor is it in violation of any provision of the Foreign Corrupt Practices Act of 1977, as amended.
Political Activity Prohibited None of the funds, materials, property or services provided directly or indirectly under the Agreement shall be used for any partisan political activity, or to further the election or defeat of any candidate for public office.
TECHNOLOGICAL CHANGE 45.1 The parties have agreed that in cases where, as a result of technological change, the services of an employee are no longer required beyond a specified date because of lack of work or the discontinuance of a function, the Work Force Adjustment Policy concluded by the parties will apply. In all other cases, the following clauses will apply:
45.2 In this Article "Technological Change" means:
Prohibition on Political Activity with City Funds In accordance with San Francisco Administrative Code Chapter 12.G, Contractor may not participate in, support, or attempt to influence any political campaign for a candidate or for a ballot measure (collectively, “Political Activity”) in the performance of the services provided under this Agreement. Contractor agrees to comply with San Francisco Administrative Code Chapter 12.G and any implementing rules and regulations promulgated by the City’s Controller. The terms and provisions of Chapter 12.G are incorporated herein by this reference. In the event Contractor violates the provisions of this section, the City may, in addition to any other rights or remedies available hereunder, (i) terminate this Agreement, and (ii) prohibit Contractor from bidding on or receiving any new City contract for a period of two (2) years. The Controller will not consider Contractor’s use of profit as a violation of this section.
Illegal or Unauthorized Payments; Political Contributions Neither the Company nor any of its Subsidiaries nor, to the best of the Company’s knowledge (after reasonable inquiry of its officers and directors), any of the officers, directors, employees, agents or other representatives of the Company or any of its Subsidiaries or any other business entity or enterprise with which the Company or any Subsidiary is or has been affiliated or associated, has, directly or indirectly, made or authorized any payment, contribution or gift of money, property, or services, whether or not in contravention of applicable law, (i) as a kickback or bribe to any Person or (ii) to any political organization, or the holder of or any aspirant to any elective or appointive public office except for personal political contributions not involving the direct or indirect use of funds of the Company or any of its Subsidiaries.
