Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.
Suspension or Termination In accordance with 24 CFR 85.43, the Grantee may suspend or terminate this Agreement if the Recipient materially fails to comply with any terms of this Agreement, which include (but are not limited to), the following:
1. Failure to comply with any of the rules, regulations or provisions referred to herein, or such statutes, regulations, executive orders, and HUD guidelines, policies or directives as may become applicable at any time;
2. Failure, for any reason, of the Recipient to fulfill in a timely and proper manner its obligations under this Agreement;
3. Ineffective or improper use of funds provided under this Agreement; or
4. Submission by the Recipient to the Grantee reports that are incorrect or incomplete in any material respect. In accordance with 24 CFR 85.44, this Agreement may also be terminated for convenience by either the Grantee or the Recipient, in whole or in part, by setting forth the reasons for such termination, the effective date, and, in the case of partial termination, the portion to be terminated. However, if in the case of a partial termination, the Grantee determines that the remaining portion of the award will not accomplish the purpose for which the award was made, the Grantee may terminate the award in its entirety.
Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions.
b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract.
(1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance.
(2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email.
(3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination.
c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.
Suspension or Debarment In addition to the representations and requirements set forth in Section C.4:
(a) The Contractor certifies for itself and Contractor Parties involved in the administration of federal or state funds that they:
(1) are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any governmental agency (federal, state or local);
(2) within a three year period preceding the effective date of this Contract, have not been convicted or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain or performing a public (federal, state or local) transaction or contract under a public transaction; for violation of federal or state antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements or receiving stolen property;
(3) are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (federal, state or local) with commission of any of the above offenses; and
(4) have not within a three year period preceding the effective date of this Contract had one or more public transactions terminated for cause or fault.
(b) Any change in the above status shall be immediately reported to the Agency.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
Suspension or Termination of Sales Consistent with standard market settlement practices, the Company or the Agent may, upon notice to the other party hereto in writing or by telephone (confirmed immediately by verifiable email), suspend any sale of Shares, and the period set forth in an Issuance Notice shall immediately terminate; provided, however, that (A) such suspension and termination shall not affect or impair either party’s obligations with respect to any Shares placed or sold hereunder prior to the receipt of such notice; (B) if the Company suspends or terminates any sale of Shares after the Agent confirms such sale to the Company, the Company shall still be obligated to comply with Section 3(b)(v) with respect to such Shares; and (C) if the Company defaults in its obligation to deliver Shares on a Settlement Date, the Company agrees that it will hold the Agent harmless against any loss, claim, damage or expense (including, without limitation, penalties, interest and reasonable legal fees and expenses), as incurred, arising out of or in connection with such default by the Company. The parties hereto acknowledge and agree that, in performing its obligations under this Agreement, the Agent may borrow Common Shares from stock lenders in the event that the Company has not delivered Shares to settle sales as required by subsection (v) above, and may use the Shares to settle or close out such borrowings. The Company agrees that no such notice shall be effective against the Agent unless it is made to the persons identified in writing by the Agent pursuant to Section 3(b)(i).
NON-SUSPENSION OR DEBARMENT CERTIFICATION The City of Xxxxxx is prohibited from contracting with or making prime or sub-awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Xxxxxx Contracts. By accepting a Contract with the City, the Vendor certifies that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non-Procurement Programs, the State of Texas, or the City of Xxxxxx.
CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION
