PROJECT OFFICE FOR THE EMPLOYER’s ENGINEER Sample Clauses

PROJECT OFFICE FOR THE EMPLOYER’s ENGINEER. (1) The Contractor shall provide, furnish, equip, insure, service, maintain and clean a detached office as detailed in sub clause 3.1.11.1 to this Specification for the exclusive use of the Employer’s Engineer. The office plan and located/position shall be approved by the Employer’s Engineer. (2) The office shall be ready for use and occupation and fully serviced within [28] days of the Appointment Date. The office shall be provided until a period of [28] days after the date of issue of the Taking-Over Certificate in respect of the whole of the Works or an earlier date if instructed by the Employer’s Engineer. Following such date, the office shall be removed from the Site. (3) The Contractor shall arrange at his own expense for the provision and disconnection on completion of power, potable water, sewerage, drainage, telephone and internet (minimum speed should be 10 Mbps for leased line with fibre optic line and minimum speed should be 50 Mbps for broad band lines with fibre optic line) to the Employer’s Engineer’s office including making all payments to utility providers for connection and use. Where a septic tank is provided, the Contractor shall be responsible for its installation, regular maintenance like emptying and the like, and removal on completion. (4) The Contractor shall submit full details of the office building to the Employer’s Engineer for approval prior to erection. The building shall be weatherproof, fire protected, heat-insulated, properly ventilated and secure. Windows shall give adequate light and ventilation [be protected with metal mosquito-proof gauze, have security bars] and have venetian, or other approved, blinds. Ceiling height shall be at least 2.4m above the floor level. All internal partition walls shall be sound insulated. Floors shall be PVC tile covered. Floors in toilets and other wet areas shall have drains. The internal decoration shall be of good standard and to the satisfaction of the Employer’s Engineer. The Contractor shall be responsible for raising the ground where necessary, grading and drainage in the vicinity of the building and providing suitable access and walkways. (5) Each room shall have at least four double gang 13 amp sockets and shall be adequately illuminated. Rooms used as offices or meeting rooms shall be air conditioned. The air conditioning shall be adequate to maintain a temperature of not more than [23oC (dry bulb) at a relative humidity of 50% during the hottest season of the year]. The noise l...
Sample 1
AutoNDA by SimpleDocs

Related to PROJECT OFFICE FOR THE EMPLOYER’s ENGINEER

  • OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • Tax Examinations Abroad 1. A Contracting Party may allow representatives of the competent authority of the other Contracting Party to enter the territory of the first-mentioned Party to interview individuals and examine records with the written consent of the persons concerned. The competent authority of the second-mentioned Party shall notify the competent authority of the first-mentioned Party of the time and place of the meeting with the individuals concerned. 2. At the request of the competent authority of one Contracting Party, the competent authority of the other Contracting Party may allow representatives of the competent authority of the first-mentioned Party to be present at the appropriate part of a tax examination in the second-mentioned Party. 3. If the request referred to in paragraph 2 is acceded to, the competent authority of the Contracting Party conducting the examination shall, as soon as possible, notify the competent authority of the other Party about the time and place of the examination, the authority or official designated to carry out the examination and the procedures and conditions required by the first-mentioned Party for the conduct of the examination. All decisions with respect to the conduct of the tax examination shall be made by the Party conducting the examination.

  • Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Search, Enquiry, Investigation, Examination And Verification a. The Property is sold on an “as is where is basis” subject to all the necessary inspection, search (including but not limited to the status of title), enquiry (including but not limited to the terms of consent to transfer and/or assignment and outstanding charges), investigation, examination and verification of which the Purchaser is already advised to conduct prior to the auction and which the Purchaser warrants to the Assignee has been conducted by the Purchaser’s independent legal advisors at the time of execution of the Memorandum. b. The intending bidder or the Purchaser is responsible at own costs and expenses to make and shall be deemed to have carried out own search, enquiry, investigation, examination and verification on all liabilities and encumbrances affecting the Property, the title particulars as well as the accuracy and correctness of the particulars and information provided. c. The Purchaser shall be deemed to purchase the Property in all respects subject thereto and shall also be deemed to have full knowledge of the state and condition of the Property regardless of whether or not the said search, enquiry, investigation, examination and verification have been conducted. d. The Purchaser shall be deemed to have read, understood and accepted these Conditions of Sale prior to the auction and to have knowledge of all matters which would have been disclosed thereby and the Purchaser expressly warrants to the Assignee that the Purchaser has sought independent legal advice on all matters pertaining to this sale and has been advised by his/her/its independent legal advisor of the effect of all the Conditions of Sale. e. Neither the Assignee nor the Auctioneer shall be required or bound to inform the Purchaser of any such matters whether known to them or not and the Purchaser shall raise no enquiry, requisition or objection thereon or thereto.

  • Other Controller Audit Any other Controller may audit SAP’s control environment and security practices relevant to Personal Data processed by SAP in line with Section 5.1 only if any of the cases set out in Section 5.1 applies to such other Controller. Such audit must be undertaken through and by Customer as set out in Section 5.1 unless the audit must be undertaken by the other Controller itself under Data Protection Law. If several Controllers whose Personal Data is processed by SAP on the basis of the Agreement require an audit, Customer shall use all reasonable means to combine the audits and to avoid multiple audits.

  • Department’s Contract Manager The Department’s Contract Manager, who is primarily responsible for the Department’s oversight of the Contract, will be identified in a separate writing to the Contractor upon Contract signing in the following format: Department’s Contract Manager Name Department’s Name Department’s Physical Address Department’s Telephone # Department’s Email Address If the Department changes the Contract Manager, the Department will notify the Contractor. Such a change does not require an amendment to the Contract.

  • Employee Verification In accordance with Neb. Rev.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!