Project Staff Contractor shall appoint to the Project Staff: (i) individuals with suitable training and skills to provide the Work, and (ii) sufficient staffing to adequately provide the Work. Contractor shall make commercially reasonable efforts consistent with sound business practices to honor the specific request of the JBE with regard to assignment of its employees. The JBE may require Contractor to remove any personnel from the Project Staff that interact with any personnel of the Judicial Branch Entities or JBE Contractors (including, without limitation, the Contractor Project Manager) upon providing to Contractor a reason (permitted by law) for such removal. Contractor may, with the JBE’s consent, continue to retain such member of the Project Staff in a role that does not interact with any personnel of the Judicial Branch Entities or
PROJECT SERVICES Landlord shall furnish services as follows:
Project Location [Insert the location of the Project, if applicable]
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $215,500.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at a P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.
Project Coordination The Engineer shall coordinate all subconsultant activity to include quality and consistency of deliverables and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
Ordering Services a) By submitting an Order to Megaport:
1. Customer warrants that the information Customer provides to Megaport in an Order is true and correct and that Megaport may rely upon it; and
2. Customer is making a binding offer to acquire the Services described in the Order on the terms set out in this Agreement, which Megaport may accept at its discretion. An agreement to supply a Service is formed on the date Megaport provisions that Service and charges apply from the Billing Commencement Date.
Project Steering Committee 1. For a sound implementation and management of the project, a steering committee shall be set up in line with provisions of the programme manual.
2. The steering committee is the decision-making body of the project and it shall be composed by representatives of the LP and all PPs duly authorised to represent the respective LP and PP institutions. It shall be chaired by the LP and it shall meet on a regular basis. Associated partners shall be invited to take part in the steering committee in an advisory capacity. External key stakeholders may also be invited to take part to one or more meetings in an observer/advisory capacity.
3. The steering committee shall at least:
a. be responsible for monitoring and validating the implementation of the project and the achievement of the planned results as in the approved application form;
b. perform the financial monitoring of the project implementation and to decide on any budget modifications as in § 11 of this agreement;
c. monitor and manage deviations of the project implementation;
d. decide on project modifications (e.g. partnership, budget, activities, and duration) if needed;
e. be responsible for the settlement of any disputes within the partnership (as stipulated in § 22 of this agreement).
4. Further aspects, including the creation of sub-groups or task forces, may be set out in the rules of procedure of the steering committee.
Construction Phase Services 3.1.1 – Basic Construction Services
Interconnection Customer (1) Interconnection Customer shall construct and, unless otherwise indicated, shall own, the following Interconnection Facilities: None
(2) In the event that, in accordance with the Interconnection Construction Service Agreement, Interconnection Customer has exercised the Option to Build, it is hereby permitted to build in accordance with and subject to the conditions and limitations set forth in that Section, the following portions of the Transmission Owner Interconnection Facilities which constitute or are part of the Customer Facility: None Ownership of the facilities built by Interconnection Customer pursuant to the Option to Build shall be as provided in the Interconnection Construction Service Agreement.
