Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Access to Property, Property’s Management, Property Lender, and Property Tenants Potential Investor agrees to not seek to gain access to any non-public areas of the Property or communicate with Property’s management employees, the holder of any financing encumbering the Property, the Property’s tenants, and the Owner’s partners in the ownership of the Property, without the prior consent of Owner or JLL, which consent may be withheld in the Owner’s sole discretion.
Access to the Property 1. We and our representatives shall only have access to the Property during the Vendor's normal business hours upon reasonable notice to the Vendor, at our sole risk and expense. Such site visits shall be conducted in the presence of a representative of the Vendor, in a manner that minimizes interference with the use of the Property and does not contravene any leases or unreasonably interfere with any Tenants. We and our representatives shall not have any communications with Tenants or their employees without the prior written approval of the Vendor and in the presence of a representative of the Vendor.
Real Property; Personal Property (a) On the Disaffiliation Date, Local Church will have full title and ownership of the Real Property and Personal Property. The parties shall ensure all necessary transfers or other transactions relating to the above properties are completed on or prior to the Disaffiliation Date. Any costs resulting from such transfers or other transactions shall be borne by Local Church. Annual Conference shall fully cooperate with Local Church, as needed and applicable, to ensure that such transfers and other transactions convey all of Annual Conference’s interest – both for itself and on behalf of The United Methodist Church – in the Real Property and Personal Property, both tangible and intangible, of Local Church.
(b) At Closing, the Annual Conference shall deliver to the Local Church: (i) the Deed(s) quitclaiming and releasing all interest of the Annual Conference in the Real Property to the Local Church; (ii) the Bill of Sale conveying all the interest of the Annual Conference in the Personal Property to the Local Church; and, (iii) a FIRPTA certificate.
Personal Property Collateral The Administrative Agent shall have received, in form and substance satisfactory to the Administrative Agent:
(i) (A) searches of UCC filings in the jurisdiction of incorporation or formation, as applicable, of each Loan Party and each jurisdiction where any Collateral is located or where a filing would need to be made in order to perfect the Collateral Agent’s security interest in the Collateral, copies of the financing statements on file in such jurisdictions and evidence that no Liens exist other than Permitted Liens and (B) tax lien, judgment and bankruptcy searches;
(ii) searches of ownership of Intellectual Property in the appropriate governmental offices and such patent/trademark/copyright filings as requested by the Administrative Agent in order to perfect the Collateral Agent’s security interest in the Intellectual Property (and certain of which searches may be provided after the Closing Date as determined by the Administrative Agent);
(iii) completed UCC financing statements for each appropriate jurisdiction as is necessary, in the Collateral Agent’s sole discretion, to perfect the Administrative Agent’s security interest in the Collateral;
(iv) stock or membership certificates, if any, evidencing the Pledged Collateral and undated stock or transfer powers duly executed in blank; in each case to the extent such Pledged Collateral is certificated;
(v) in the case of any personal property Collateral located at premises leased by a Loan Party and set forth on Schedule 5.21(g), such estoppel letters, consents and waivers from the landlords of such real property to the extent required to be delivered in connection with Section 6.14 (such letters, consents and waivers shall be in form and substance satisfactory to the Administrative Agent, it being acknowledged and agreed that any Landlord Waiver is satisfactory to the Administrative Agent);
(vi) to the extent required to be delivered, filed, registered or recorded pursuant to the terms and conditions of the Collateral Documents, all instruments, documents and chattel paper in the possession of any of the Loan Parties, together with allonges or assignments as may be necessary or appropriate to create and perfect the Administrative Agent’s and the Lenders’ security interest in the Collateral; and
(vii) Qualifying Control Agreements satisfactory to the Administrative Agent to the extent required to be delivered pursuant to Section 6.14.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Personal Property In addition to the real property described in Section II, the Seller shall include the following personal property:
Property Use The Property shall be used only for industrial, warehouse and office purposes, and for no other use without the prior written consent of Lender, which consent may be withheld in Lender's sole and absolute discretion.
Access to Project Site Redeveloper shall permit the representatives of the City to enter Project Site at any and all reasonable times, as the City may deem necessary for the purposes of this Redevelopment Agreement, including but not limited to work and inspection of all work being performed in connection with the construction of the Redeveloper Improvements. Similarly, the City shall permit Redeveloper such entry upon the public rights of way for such purposes. No compensation shall be payable nor shall any charges be made in any form by any party for the access or inspection provided for in this Section. The City’s right of access granted under this Section shall terminate upon issuance by the City of the Redeveloper’s Certificate of Completion of Redeveloper Improvements. Notwithstanding the above, Redeveloper shall not be relieved of the provisions contained in Chapter 14.29 of the Lincoln Municipal Code regarding the use of streets for private construction purposes.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
