Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.
Review of Materials During the term of this Agreement, Client shall ensure that all prospectuses, statements of additional information, registration statements, proxy statements, reports to shareholders, advertising and sales literature or other materials prepared for distribution to Fund shareholders or the public, which refer to the Subadviser in any way, prepared by employees or agents of Client or its affiliates are consistent with information previously provided by Subadviser. Subadviser shall promptly notify the Client of any changes to information pertaining to the Subadviser and stated in the materials described in this Section 6(g).
Independence from Material Breach Determination Except as set forth in Section X.D.1.c, these provisions for payment of Stipulated Penalties shall not affect or otherwise set a standard for OIG’s decision that Xxxxx has materially breached this IA, which decision shall be made at OIG’s discretion and shall be governed by the provisions in Section X.D, below.
Adverse Weather Shall be only weather that satisfies all of the following conditions: (1) unusually severe precipitation, sleet, snow, hail, or extreme temperature or air conditions in excess of the norm for the location and time of year it occurred based on the closest weather station data averaged over the past five years, (2) that is unanticipated and would cause unsafe work conditions and/or is unsuitable for scheduled work that should not be performed during inclement weather (i.e., exterior finishes), and (3) at the Project.
Deviations Deviations from the drawings and the dimensions therein given, whether or not error is believed to exist, shall be made only after written authority is obtained from the County, and shall be documented within the Detailed Scope of Work for the specific Job Order.
Failure to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
Problems To endeavour to resolve in a fair and just manner any problems, grievances or difficulties which may be encountered while you volunteer with us;
Reasonable Suspicion Testing All Employees Performing Safety-Sensitive Functions
A. Reasonable suspicion testing for alcohol or controlled substances may be directed by the Employer for any employee performing safety-sensitive functions when there is reason to suspect that alcohol or controlled substance use may be adversely affecting the employee’s job performance or that the employee may present a danger to the physical safety of the employee or another.
B. Specific objective grounds must be stated in writing that support the reasonable suspicion. Examples of specific objective grounds include but are not limited to:
1. Physical symptoms consistent with alcohol and/or controlled substance use;
2. Evidence or observation of alcohol or controlled substance use, possession, sale, or delivery; or
3. The occurrence of an accident(s) where a trained manager, supervisor or lead worker suspects alcohol or other controlled substance use may have been a factor.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
