Quarterly Account Review Sample Clauses

Quarterly Account Review. Based on the service level expectations set forth in this Service Model and Service Level Agreement, ADP will present a Quarterly Account Review to the AOC. The presentation will include, but is not limited to: • Number of calls to the Service Team for the previous quarter • Summary of ADP transaction surveys received from the Courts for the previous quarter • Summary of the bi-annual quality surveys received from the Courts for the previous quarter • Summary of the conversion implementation surveys received from the Courts for the previous quarter • Review of the status and service level agreement terms based on service quality metrics that have been established for the program measurements. The session will also provide an open forum to outline any current concerns from ADP and/or the AOC, upcoming Court conversions and projects/plans, and feedback from any AOC surveys that may have been provided to the Courts.
AutoNDA by SimpleDocs

Related to Quarterly Account Review

  • Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.

  • Quarterly Sales Reports The Contractor shall submit a completed Quarterly Sales Report electronically, in the required format, to the Department’s Contract Manager within thirty (30) calendar days after close of each quarter. The quarterly sales report can be found here: xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. The Contract Quarterly Sales Report will include all sales and orders associated with this Contract from Customers received during the reporting period. Initiation and submission of the Sales Report is the responsibility of the Contractor without prompting or notification from the DMS Contract Manager. Failure to provide the quarterly sales report will result in the imposition of financial consequences and may result in the Contractor being found in default and the termination of the Contract. Initiation and submission of the quarterly sales report are the responsibility of the Contractor without prompting or notification by the Department. Sales will be reviewed on a quarterly basis. If no sales are recorded during the period, the Contractor must submit a report stating that there was no activity. If no sales are recorded in two consecutive quarters, the Contractor may be placed in probationary status or the Department may terminate the Contract. Quarter 1 – (July-September) – due 30 calendar days after the close of the period Quarter 2 – (October-December) – due 30 calendar days after the close of the period Quarter 3 – (January-March) – due 30 calendar days after the close of the period Quarter 4 – (April-June) due 30 calendar days after the close of the period Exceptions may be made if a delay in submitting reports is attributable to circumstances that are clearly beyond the control of the Contractor. The burden of proof of unavoidable delay shall rest with the Contractor and shall be supplied in a written form and submitted to the Department. The Department reserves the right to request additional sales information as needed.

  • Quarterly Progress Reports The goal of this task is to periodically verify that satisfactory and continued progress is made towards achieving the objectives of this Agreement on time and within budget. The objectives of this task are to summarize activities performed during the reporting period, to identify activities planned for the next reporting period, to identify issues that may affect performance and expenditures, and to form the basis for determining whether invoices are consistent with work performed. The Recipient shall: • Prepare a Quarterly Progress Report which summarizes all Agreement activities conducted by the Recipient for the reporting period, including an assessment of the ability to complete the Agreement within the current budget and any anticipated cost overruns. Progress reports are due to the CAM the 10th day of each January, April, July, and October. The Quarterly Progress Report template can be found on the ECAMS Resources webpage available at xxxxx://xxx.xxxxxx.xx.xxx/media/4691. Product: • Quarterly Progress Reports

  • Periodic Review The General Counsel shall periodically review the Procurement Integrity Procedures with OSC personnel in order to ascertain potential areas of exposure to improper influence and to adopt desirable revisions for more effective avoidance of improper influences.

  • Post Review With respect to each contract not governed by paragraph 2 of this Part, the procedures set forth in paragraph 4 of Appendix 1 to the Guidelines shall apply.

  • Periodic Reviews During January of each year during the term hereof, the Board of Directors of the Company shall review Executive's Annual Salary, bonus, stock options, and additional benefits then being provided to Executive. Following each such review, the Company may in its discretion increase the Annual Salary, bonus, stock options, and benefits; however, the Company shall not decrease such items during the period Executive serves as an employee of the Company. Prior to November 30th of each year during the term hereof, the Board of Directors of the Company shall communicate in writing the results of such review to Executive.

  • ANNUAL MASTER CONTRACT SALES REPORT Contractor shall provide to Enterprise Services a detailed annual Master Contract sales report. Such report shall include, at a minimum: Product description, part number or other Product identifier, per unit quantities sold, and Master Contract price. This report must be provided in an electronic format that can be read by MS Excel.

  • Extended Reporting Period If any required insurance coverage is on a claims-made basis (rather than occurrence), Contractor shall maintain such coverage for a period of no less than three (3) years following expiration or termination of the Master Contract.

  • Quarterly As of the last day of each Fiscal Quarter.

  • Program Review The Contracting Officer or other authorized government representative may hold semi- annual program review meetings. Such meetings will be held via telecom or video teleconferencing. However, the Government reserves the right to request a meeting in person. The meetings will include all BPA holders, representatives from prospective customer agencies, a combination of current and prospective customer agencies, or individual BPA holders. Some Federal Government Agencies and any approved State, Local and Tribal agencies may establish a central program management function. Such users may require their primary suppliers to participate in agency program review meetings on a periodic basis, at no additional cost to the Government.

Time is Money Join Law Insider Premium to draft better contracts faster.