R equests for Additional Compensation or Time Sample Clauses

R equests for Additional Compensation or Time. If Design-Builder reasonably believes adjustments to the Contract Documents that would lead to a Change Order are required due to clarifications or instructions issued by Owner Parties in response to the Design-Builder’s notices or requests for information, Design-Builder shall submit a written request to Owner Parties, setting forth the nature and specific extent of the request, including all time and cost impacts, as soon as possible, but in no event later than twenty-one (21) Days after Design-Builder’s receipt of the clarifications or instructions issued. If Owner Parties deny Design-Builder’s request for additional compensation, and Design-Builder reasonably believes such denial was in error, the Design-Builder may file a Claim in accordance with Article 12 of these General Conditions.
Sample 1
AutoNDA by SimpleDocs

Related to R equests for Additional Compensation or Time

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Compensation for Holidays Worked a. With the exception of the provisions in Section C.2.b., below, an employee required to work on a holiday listed above shall be paid at the employee's regular straight-time rate of pay for the hours actually worked. In addition, an eligible employee shall receive either compensatory time off or holiday pay at the option of the University at the regular straight-time rate, including any shift differential.

  • Claims for Additional Costs 11.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum not related to a requested change, it shall give the Owner and the A/E written notice thereof within twenty-one (21) days after the occurrence of the event giving rise to such claim, but, in any case before proceeding to execute the work considered to give rise to the additional cost or time, except in an emergency endangering life or property in which case the Contractor shall act in accordance with Article 7.2.1. No such claim shall be valid unless so made. If the Owner and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined as set forth under Article 15. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • HOLIDAY COMPENSATION FOR TIME WORKED 126. Employees required by their respective appointing officers to work on any of the above specified or substitute holidays, excepting Fridays observed as holidays in lieu of holidays falling on Saturday, shall be paid extra compensation of one additional day's pay at time- and-one-half the usual rate in the amount of 12 hours pay for 8 hours worked or a proportionate amount for less than 8 hours worked provided, however, that at the employee's request and with the approval of the appointing officer, an employee may be granted compensatory time off in lieu of paid overtime as provided for elsewhere in this contract. 127. Executive, administrative and professional employees designated in the Annual Salary Ordinance with the "Z" symbol shall not receive extra compensation for holiday work but may be granted time off equivalent to the time worked at the rate of-one-and-one-half times for work on the holiday.

  • Compensation for Work on Holidays 1. An employee who is required to work on Columbus Day, Veteran's Day, Day after Thanksgiving, Xxxxxx Xxxxxx Xxxx, Xx.'s Birthday, Xxxxxxx's Birthday or Washington's Birthday and who meets the eligibility requirements contained herein shall receive his or her regular pay for each hour worked. Work performed on a holiday which is overtime as defined in Article I, Section 1.A., shall be compensated as provided in Article I, Section 2.C.1.

  • Compensatory Time for Overtime Eligible Employees A. Compensatory Time Eligibility Compensatory time off may be earned in lieu of cash only when an institution and the employee agree. Compensatory time must be granted at the rate of one and one half (1-1/2) hours of compensatory time for each hour of overtime worked.

Time is Money Join Law Insider Premium to draft better contracts faster.