Reduction or Relocation of the Premises Sample Clauses

Reduction or Relocation of the Premises. In addition to any other right of the Authority herein, the Authority may, at any time during the Term of this Contract and upon one hundred twenty (120) days prior written notice to the Contractor, require the Contractor to surrender all or any portion of the Premises in order to accommodate the construction of an on-Airport Consolidated Rental Car Facility as further defined in Section 4.01. In such event, the Authority shall in its reasonable discretion provide the Contractor with substitute premises which the Authority determines to be reasonably comparable to the portion of the Premises surrendered.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Reduction or Relocation of the Premises. In addition to any other right of the Authority herein, the Authority may, at any time during the Operating Period of this Contract and upon sixty (60) days prior written notice to the Contractor, require the Contractor to surrender all or any portion of the Premises in order to accommodate a change in the design or use of the Airport's facilities. Subject to 2.03 below, in such event the Authority shall in its reasonable discretion either (i) provide the Contractor with substitute premises which the Authority determines to be reasonably comparable to the portion of the Premises surrendered or (ii) grant the Contractor an equitable reduction in the Minimum Annual Guarantee payable by the Contractor to the Authority hereunder. If substitute premises are provided, the Authority shall purchase any Fixed Improvements installed by the Contractor with the Authority’s approval that cannot reasonably be moved to the substitute Premises. The amount to be paid for the Fixed Improvements shall be the unamortized value of the Fixed Improvements existing at the date the Contractor moves to the substitute Premises. For purposes of calculating the Fixed Improvement purchase price, the Fixed Improvements shall be amortized on a straight-line basis over the number of months remaining in the current Contract at the time the Fixed Improvements were completed. Fixed Improvements installed prior to the commencement of this Contract shall not be purchased by the Authority. The Authority shall reimburse the Contractor for the reasonable direct costs of moving to the substitute Premises.
Sample 1Sample 2
Reduction or Relocation of the Premises. 21.01 Landlord shall have the right, upon not less than 30 days’ notice to Tenant, to recapture a portion or portions of the Premises, solely for the purpose of (a) installing additional elevator(s) in the Building, together with such space as may be required for lobbies and other common areas, (b) improving the Base Building, or (c) constructing public corridors to create access to rentable space now existing or to be constructed in the future on the floor on which the Premises are located (any or all of the foregoing work, "Building Improvements"). The amount of such recaptured space which may be taken by Landlord pursuant to this Section 21.01 shall be limited to such space as is reasonably and actually required for the proper installation, access and operation of such Building Improvements. Tenant shall provide Landlord with access to the Premises to perform the work to install and maintain the Building Improvements, including the right to take all necessary materials and equipment into the Premises, without the same constituting an eviction, and Tenant shall not be entitled to any abatement of Rent while such work is in progress or any damages by reason of loss or interruption of business or otherwise unless the Landlord work exceeds thirty (30) days in which case Tenant’s Rent shall be reduced by the proportionate area of the Premises impacted, inaccessible or unusable due to noise. Landlord shall use reasonable efforts to minimize interference with Tenant's access to and use and occupancy of the Premises in making any Building Improvements; provided, however, that Landlord shall have no obligation to employ contractors or labor at overtime or other premium pay rates or to incur any other overtime costs or additional expenses whatsoever. Promptly following the completion of any Building Improvements, Landlord shall make such repairs to and restoration of the Premises as may be reasonably required as a direct result thereof. Upon the date set forth for such recapture in Landlord's notice described above, the Lease shall be deemed automatically amended by the deletion of such recaptured space from the Premises, Base Rent and Additional Rent shall be reduced in the proportion which the area of the part of the Premises so recaptured bears to the total area of the Premises immediately prior thereto, and Tenant shall promptly vacate and surrender such portion of the Premises to Landlord, and except as otherwise specifically set forth in this Section 21.01,...
Sample 1

Related to Reduction or Relocation of the Premises

  • Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:

  • RELOCATION OF PREMISES Landlord shall have the right to relocate the Premises to another part of the Building in accordance with the following:

  • Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:

  • TENANT'S USE OF THE PREMISES Tenant shall use the Premises solely for the purposes set forth in Tenant's Use Clause. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall, by reason of the nature of Tenant's use or occupancy of the Premises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Insurance Services Office or any other organization performing a similar function. Tenant shall

  • RELOCATION OF TENANT Upon prior written notice to Tenant, Landlord shall have the right to relocate Tenant to new space (the “Relocation Space”) within the Project that is comparable in size, utility, and condition to the Premises, including similar Tenant Improvements. Such relocation will be effective on a date specified by Landlord in its relocation notice, which date will not be less than ninety (90) days after the date of such notice. If Landlord relocates Tenant, Landlord will reimburse Tenant for Tenant’s reasonable out-of-pocket expenses for moving Tenant’s furniture, equipment, and supplies from the Premises to the Relocation Space, and other reasonable relocation costs. Tenant shall be entitled to concurrently occupy both the Premises and Relocation Space for a period not to exceed twenty (20) days in order to effectuate its relocation in a minimally non-disruptive manner. Upon such relocation, the Relocation Space will be deemed to be the Premises and the terms of this Lease will remain in full force and effect and apply to the Relocation Space. No amendment or other instrument shall be necessary to effectuate the relocation contemplated by this Section; however, if requested by Landlord, Tenant shall execute and deliver to Landlord an appropriate amendment document within twenty (20) days after Landlord’s request therefor. If Tenant fails to execute and deliver such relocation amendment within such time period, or if Tenant fails to relocate within the time period stated in Landlord’s relocation notice to Tenant (or, if the Relocation Space is not available on the date specified in Landlord’s relocation notice, as soon thereafter as the Relocation Space becomes available and is tendered to Tenant in the condition required by this Lease), then, in addition to Landlord’s other remedies set forth in this Lease, at law and/or in equity, Landlord may terminate this Lease by notifying Tenant in writing thereof at least sixty (60) days prior to the termination date contained in Landlord’s termination notice. Landlord’s exercise of its rights as permitted by this Section shall not (a) constitute a constructive eviction, an interference with Tenant’s right of quiet enjoyment, or a disturbance of Tenant’s right to use the Premises; and (b) subject Landlord to damages, including, but not limited to, damages for loss of goodwill, business, or profits. Time is of the essence with respect to Tenant’s obligations under this Section.

  • Operation of the Property During the Term, NAI shall operate the Property in a good and workmanlike manner and substantially in compliance with all Applicable Laws and will pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written notice given to NAI or BNPLC by any governmental authority, then for purposes of the preceding sentence, NAI shall be considered not to have maintained the Property "substantially in accordance with Applicable Laws" whether or not the noncompliance would be substantial in the absence of the notice.) During the Term, NAI shall not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. During the Term, to the extent that any of the following would, individually or in the aggregate, materially and adversely affect the value of the Property or NAI's use, occupancy or operations on the Property, NAI shall not, without BNPLC's prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. If (A) a change in the zoning or other Applicable Laws affecting the permitted use or development of the Property shall occur after the Base Rent Commencement Date that reduces the value of the Property, or (B) conditions or circumstances on or about the Property are discovered after the Base Rent Commencement Date (such as the presence of an endangered species) which substantially impede development and thereby reduce the value of the Property, and if after any such reduction under clause (A) or (B) preceding the Current AS IS Market Value of the Property is less than sixty percent (60%) of Stipulated Loss Value, then NAI shall pay BNPLC upon request the amount by which Current AS IS Market Value is less than sixty percent (60%) of Stipulated Loss Value, for application as a Qualified Prepayment. During the Term, NAI shall not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI shall not do any act whereby the market value of the Property may reasonably be expected to be materially lessened. During the Term, if NAI receives a written notice or claim from any federal, state or other governmental entity that the Property is not in compliance in any material respect with any Applicable Law, or that any action may be taken against the owner of the Property because the Property does not comply with Applicable Law, NAI shall promptly furnish a copy of such notice or claim to BNPLC. Notwithstanding the foregoing, NAI may in good faith, by appropriate proceedings, contest the validity and applicability of any Applicable Law with respect to the Property, and pending such contest NAI shall not be deemed in default hereunder because of the violation of such Applicable Law, if NAI diligently prosecutes such contest to completion in a manner reasonably satisfactory to BNPLC, and if NAI promptly causes the Property to comply with any such Applicable Law upon a final determination by a court of competent jurisdiction that the same is valid and applicable to the Property; provided, however, in any event such contest shall be concluded and the violation of such Applicable Law must be corrected by NAI and any claims asserted against BNPLC or the Property because of such violation must be paid by NAI, all prior to the earlier of (i) the date that any criminal prosecution is instituted or overtly threatened against BNPLC or any of its directors, officers or employees because of such violation, (ii) the date that any action is taken by any governmental authority against BNPLC or any property owned by BNPLC (including the Property) because of such violation, or (iii) a Designated Sale Date upon which, for any reason, NAI or an Affiliate of NAI or any Applicable Purchaser shall not purchase BNPLC's interest in the Property pursuant to the Purchase Agreement for a price to BNPLC (when taken together with any additional payments made by NAI pursuant to Paragraph 1(A)(2) of the Purchase Agreement, in the case of a purchase by an Applicable Purchaser) equal to the Break Even Price.

  • Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.

  • Damage Destruction or Condemnation If the Dock or any portion thereof is at any time destroyed or damaged by a casualty, or if any portion of the Dock or adjacent parcels are taken pursuant to the exercise or threatened exercise of the power of eminent domain (including a conveyance in lieu thereof), Port may elect to terminate this Agreement.

  • Acceptance of the Premises By entry and taking possession of the -------------------------- Premises pursuant to this Lease, Tenant accepts the Premises as being in good and sanitary order, condition and repair and accepts the Premises in their condition existing as of the date of such entry, and Tenant further accepts the tenant improvements to be constructed by Landlord, if any, as being completed in accordance with the plans and specifications for such improvements, except for punch list items. Tenant acknowledges that neither Landlord nor Landlord's agents has made any representation or warranty as to the suitability of the Premises to the conduct of Tenant's business. Any agreements, warranties or representations not expressly contained herein shall in no way bind either Landlord or Tenant, and Landlord and Tenant expressly waive all claims for damages by reason of any statement, representation, warranty, promise or agreement, if any, not contained in this Lease. This Lease constitutes the entire understanding between the parties hereto and no addition to, or modification of, any term or provision of this Lease shall be effective until set forth in a writing signed by both Landlord and Tenant.

Time is Money Join Law Insider Premium to draft better contracts faster.