Relationship to DISTRICT. CONSULTANT and DISTRICT accept the relationship of trust and confidence established between them by the terms of this Agreement, and CONSULTANT agrees to use its professional skill and judgment and to cooperate with the DISTRICT in its responsibility to provide the Services in accordance with the Contract Documents by the completion date established by DISTRICT.
Relationship to DISTRICT. ARCHITECT and DISTRICT accept the relationship of trust and confidence established between them by the terms of this Agreement, and ARCHITECT agrees to use its professional skill and judgment and to cooperate with the DISTRICT and the Contractor(s) in its responsibility to construct the Project in accordance with the Construction Contract and Contract Documents by the established completion date for not more than the Construction budget established by DISTRICT.
Relationship to DISTRICT. The SAC and its subcommittees will be accountable to the District Superintendent and central administration for policies congruent with the strategic development of the District. They are specifically required to construct and ensure the establishment and alignment of student behavior plans, professional staff development plans and other plans for their sites that reflect the strategic direction of the District
