Repair, Replacement And Rehabilitation, Contingency And Capital Investment Program The Operator’s obligation to Sample Clauses

Repair, Replacement And Rehabilitation, Contingency And Capital Investment Program The Operator’s obligation to carry out all repair, replacement and rehabilitation shall include all repair, replacement or rehabilitation related to, a. the New Facility or any part thereof; including, b. the leachate collection, transfer and treatment system; c. the surface water management system; d. the groundwater management system; and e. the landfill gas management system f. the Site or any part thereof; and g. the Operator’s Equipment (Operations), h. during the term of the Contract. The Operator’s obligation to carry out repair, replacement and rehabilitation shall exclude only a repair, replacement or rehabilitation that was directly caused as a result of a Force Majeure event, reasonably unforeseeable or directly caused as a result of a War Risk.
Sample 1
AutoNDA by SimpleDocs

Related to Repair, Replacement And Rehabilitation, Contingency And Capital Investment Program The Operator’s obligation to

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

  • Property Management Agreement The Property Management Agreement is in full force and effect and, to Borrower's Knowledge, there are no defaults thereunder by any party thereto and no event has occurred that, with the passage of time and/or the giving of notice would constitute a default thereunder.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Management of REO Property (a) Prior to the acquisition by it of title to a Mortgaged Property (other than a Mortgaged Property that secures an Outside Serviced Loan Combination), the Special Servicer shall review the operation of such Mortgaged Property and determine the nature of the income that would be derived from such property if it were acquired by the Trust Fund. If the Special Servicer determines from such review that: (i) None of the income from Directly Operating such Mortgaged Property would be subject to tax as "net income from foreclosure property" within the meaning of the REMIC Provisions or would be subject to the tax imposed on "prohibited transactions" under Section 860F of the Code (either such tax referred to herein as an "REO Tax"), then such Mortgaged Property may be Directly Operated by the Special Servicer as REO Property; (ii) Directly Operating such Mortgaged Property as REO Property could result in income from such property that would be subject to an REO Tax, but that a lease of such property to another party to operate such property, or the performance of some services by an Independent Contractor with respect to such property, or another method of operating such property would not result in income subject to an REO Tax, then the Special Servicer may (provided that in the good faith and reasonable judgment of the Special Servicer, it is commercially reasonable) acquire such Mortgaged Property as REO Property and so lease or operate such REO Property; or (iii) It is reasonable to believe that Directly Operating such property as REO Property could result in income subject to an REO Tax and that no commercially reasonable means exists to operate such property as REO Property without the Trust Fund incurring or possibly incurring an REO Tax on income from such property, the Special Servicer shall deliver to the Tax Administrator, in writing, a proposed plan (the "Proposed Plan") to manage such property as REO Property. Such plan shall include potential sources of income, and, to the extent reasonably possible, estimates of the amount of income from each such source. Upon request of the Special Servicer, the Tax Administrator shall advise the Special Servicer of the Tax Administrator's federal income tax reporting position with respect to the various sources of income that the Trust Fund would derive under the Proposed Plan. After receiving the information described in the preceding sentence from the Tax Administrator, the Special Servicer shall implement the Proposed Plan (after acquiring the respective Mortgaged Property as REO Property), with any amendments required to be made thereto as a result of the Tax Administrator's tax reporting position. The Special Servicer's decision as to how each Administered REO Property shall be managed and operated shall be based on the Servicing Standard and, further, based on the good faith and reasonable judgment of the Special Servicer as to which means would be in the best interest of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)), as a collective whole, by maximizing (to the extent commercially reasonable and consistent with Section 3.17(b)) the net after-tax REO Revenues received with respect to such property without materially impairing the Special Servicer's ability to promptly sell such property for a fair price. In connection with performing their respective duties under this Section 3.17(a), both the Special Servicer and the Tax Administrator may consult with counsel and tax accountants, the reasonable cost of which consultation shall be covered by, and be reimbursable as, a Servicing Advance to be made by the Special Servicer. (b) If title to any Administered REO Property is acquired, the Special Servicer shall manage, conserve, protect and operate such REO Property for the benefit of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) solely for the purpose of its prompt disposition and sale in a manner that does not and will not: (i) cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code; or (ii) except as contemplated by Section 3.17(a), either result in the receipt by any REMIC Pool of any "income from non-permitted assets" within the meaning of Section 860F(a)(2)(B) of the Code or result in an Adverse REMIC Event or an Adverse Grantor Trust Event. Subject to the foregoing, however, the Special Servicer shall have full power and authority to do any and all things in connection therewith as are consistent with the Servicing Standard and, consistent therewith, shall withdraw from the related REO Account, to the extent of amounts on deposit therein with respect to any Administered REO Property, funds necessary for the proper operation, management, maintenance and disposition of such REO Property, including: (i) all insurance premiums due and payable in respect of such REO Property; (ii) all real estate taxes and assessments in respect of such REO Property that may result in the imposition of a lien thereon; (iii) any ground rents in respect of such REO Property; and (iv) all costs and expenses necessary to maintain, lease, sell, protect, manage, operate and restore such REO Property. To the extent that amounts on deposit in the related REO Account in respect of any Administered REO Property are insufficient for the purposes set forth in the preceding sentence with respect to such REO Property, the Master Servicer shall, at the direction of the Special Servicer, make Servicing Advances in such amounts as are necessary for such purposes unless the Master Servicer determines, in accordance with the Servicing Standard, that such payment would be a Nonrecoverable Advance; provided, however, that the Master Servicer may make any such Servicing Advance without regard to recoverability if it is a necessary fee or expense incurred in connection with the defense or prosecution of legal proceedings. (c) Without limiting the generality of the foregoing, the Special Servicer shall not, with respect to any Administered REO Property: (i) enter into, renew or extend any New Lease with respect to such Administered REO Property, if the New Lease, by its terms would give rise to any income that does not constitute Rents from Real Property; (ii) permit any amount to be received or accrued under any New Lease other than amounts that will constitute Rents from Real Property; (iii) authorize or permit any construction on such Administered REO Property, other than the completion of a building or other improvement thereon, and then only if more than 10% of the construction of such building or other improvement was completed before default on the related Serviced Mortgage Loan became imminent, all within the meaning of Section 856(e)(4)(B) of the Code; or (iv) Directly Operate, or allow any other Person, other than an Independent Contractor, to Directly Operate such Administered REO Property on any date more than 90 days after the related REO Acquisition; unless, in any such case, the Special Servicer has obtained an Opinion of Counsel (the cost of which shall be paid by the Master Servicer, at the direction of the Special Servicer, and shall be reimbursable as a Servicing Advance) to the effect that such action would not cause such Administered REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code at any time that it is held by a REMIC Pool, in which case the Special Servicer may take such actions as are specified in such Opinion of Counsel. (d) The Special Servicer may contract with any Independent Contractor for the operation and management of any Administered REO Property; provided that: (i) the terms and conditions of any such contract shall not be inconsistent herewith and shall reflect an agreement reached at arm's length; (ii) the fees of such Independent Contractor (which shall be expenses of the Trust Fund and, in the case of any Administered REO Property that relates to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) shall be reasonable and customary in consideration of the nature and locality of such Administered REO Property; (iii) except as permitted under Section 3.17(a), any such contract shall require, or shall be administered to require, that the Independent Contractor, in a timely manner, (A) pay out of related REO Revenues all costs and expenses incurred in connection with the operation and management of such Administered REO Property, including those listed in Section 3.17(b) above, and (B) except to the extent that such revenues are derived from any services rendered by the Independent Contractor to tenants of such Administered REO Property that are not customarily furnished or rendered in connection with the rental of real property (within the meaning of Section 1.856-4(b)(5) of the Treasury regulations or any successor provision), remit all related revenues collected (net of its fees and such costs and expenses) to the Special Servicer upon receipt; (iv) none of the provisions of this Section 3.17(d) relating to any such contract or to actions taken through any such Independent Contractor shall be deemed to relieve the Special Servicer of any of its duties and obligations hereunder with respect to the operation and management of such Administered REO Property; and (v) the Special Servicer shall be obligated with respect thereto to the same extent as if it alone were performing all duties and obligations in connection with the operation and management of such Administered REO Property. The Special Servicer shall be entitled to enter into any agreement with any Independent Contractor performing services for it related to its duties and obligations under Section 3.16 and this Section 3.17 for indemnification of the Special Servicer by any such Independent Contractor, and nothing in this Agreement shall be deemed to limit or modify such indemnification. No agreement entered into pursuant to this Section 3.17(d) shall be deemed a Sub-Servicing Agreement for purposes of Section 3.22. (e) Notwithstanding anything to the contrary, this Section 3.17 shall not apply to any Outside Administered REO Property.

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Discretionary Investment Management Services The Adviser shall act as investment adviser with respect to each Fund. In such capacity, the Adviser shall, subject to the supervision of the Board, regularly provide each Fund with investment research, advice and supervision and shall furnish continuously an investment program for each Fund, consistent with the respective investment objectives and policies of each Fund. The Adviser shall determine, from time to time, what securities shall be purchased for each Fund, what securities shall be held or sold by each Fund and what portion of each Fund’s assets shall be held uninvested in cash, subject always to the provisions of the Trust’s Agreement and Declaration of Trust (“Declaration of Trust”), as amended and supplemented (the “Declaration of Trust”), Bylaws and its registration statement on Form N-1A (the “Registration Statement”) under the 1940 Act, and under the Securities Act of 1933, as amended (the “1933 Act”), as filed with the Securities and Exchange Commission (the “Commission”), and with the investment objectives, policies and restrictions of each Fund, as each of the same shall be from time to time in effect. To carry out such obligations, and to the extent not prohibited by any of the foregoing, the Adviser shall exercise full discretion and act for each Fund in the same manner and with the same force and effect as each Fund itself might or could do with respect to purchases, sales or other transactions, as well as with respect to all other such things necessary or incidental to the furtherance or conduct of such purchases, sales or other transactions. No reference in this Agreement to the Adviser having full discretionary authority over each Fund’s investments shall in any way limit the right of the Board, in its sole discretion, to establish or revise policies in connection with the management of a Fund’s assets or to otherwise exercise its right to control the overall management of a Fund.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Title, Management and Disposition of REO Property In the event that title to any Mortgaged Property is acquired in foreclosure or by deed in lieu of foreclosure, the deed or certificate of sale shall be taken, pursuant to a limited power of attorney in the form attached hereto as Exhibit H, in the name of the Trustee or its nominee (which in no event shall be the Special Servicer) in trust for the benefit of the Certificateholders, or in the event the Trustee is not authorized or permitted to hold title to real property in the state where the REO Property is located, or would be adversely affected under the “doing business” or tax laws of such state by so holding title, the deed or certificate of sale shall be taken in the name of such Person or Persons as shall be consistent with an Opinion of Counsel obtained by the Special Servicer (with a copy delivered to the Trustee) from any attorney duly licensed to practice law in the state where the REO Property is located. Any such Opinion of Counsel will be deemed a Servicing Advance, reimbursable to the Special Servicer in accordance with Section 3.04. The Person or Persons holding such title other than the Trustee shall acknowledge in writing that such title is being held as nominee for the Trustee. The Special Servicer shall manage, conserve, protect and operate each REO Property for the Trustee solely for the purpose of its prompt disposition and sale. The Special Servicer, either itself or through an agent selected by the Special Servicer, shall manage, conserve, protect and operate the REO Property in the same manner that it manages, conserves, protects and operates other foreclosed property for its own account, and in the same manner that similar property in the same locality as the REO Property is managed. The Special Servicer shall attempt to sell the same (and may temporarily rent the same for a period not greater than one year, except as otherwise provided below) on such terms and conditions as the Special Servicer deems to be in the best interest of the Trustee and the Certificateholders. In the event that the Trust Fund acquires any REO Property in connection with a default or imminent default on a Transferred Mortgage Loan, the Special Servicer shall dispose of such REO Property not later than the end of the third taxable year after the year of its acquisition by the Trust Fund unless the Special Servicer has applied for and received a grant of extension from the Internal Revenue Service (and provide a copy of the same to the Master Servicer and the Trustee) to the effect that, under the REMIC Provisions and any relevant proposed legislation and under applicable state law, the applicable Trust REMIC may hold REO Property for a longer period without adversely affecting the REMIC status of such REMIC or causing the imposition of a federal or state tax upon such REMIC and has notified the Master Servicer and the Trustee of such extension by providing a copy of the application and the grant of such extension to the Trustee and the Master Servicer. If the Special Servicer has received such an extension (and provided a copy of the same to the Master Servicer and the Trustee), then the Special Servicer shall continue to attempt to sell the REO Property for its fair market value for such period longer than three years as such extension permits (the “Extended Period”). If the Special Servicer has not received such an extension and the Special Servicer is unable to sell the REO Property within the period ending three months before the end of such third taxable year after its acquisition by the Trust Fund or if the Special Servicer has received such an extension, and the Special Servicer is unable to sell the REO Property within the period ending three months before the close of the Extended Period, the Special Servicer shall, before the end of the three-year period or the Extended Period, as applicable, (i) purchase such REO Property at a price equal to the REO Property’s fair market value or (ii) auction the REO Property to the highest bidder (which may be the Special Servicer) in an auction reasonably designed to produce a fair price prior to the expiration of the three-year period or the Extended Period, as the case may be. The Trustee shall sign any document reasonably requested by, and at the expense of, the Special Servicer, or take any other action reasonably requested by the Special Servicer which would enable the Special Servicer, on behalf of the Trust Fund, to request such grant of extension. In all cases, the disposition of REO Property shall be carried out by the Special Servicer at such price, and upon such terms and conditions, as the Servicer deems to be in the best interests of the Trust Fund. Notwithstanding any other provisions of this Agreement, no REO Property acquired by the Trust Fund shall be rented (or allowed to continue to be rented) or otherwise used by or on behalf of the Trust Fund in such a manner or pursuant to any terms that would: (i) cause such REO Property to fail to qualify as “foreclosure property” within the meaning of Section 860G(a)(8) of the Code; or (ii) subject any Trust REMIC to the imposition of any federal income taxes on the income earned from such REO Property, including any taxes imposed by reason of Sections 860F or 860G(c) of the Code, unless the Special Servicer has agreed to indemnify and hold harmless the Trust Fund with respect to the imposition of any such taxes. The Special Servicer shall also maintain on each REO Property fire and hazard insurance with extended coverage in amount which is at least equal to the maximum insurable value of the improvements which are a part of such property, liability insurance and, to the extent required and available under the Flood Disaster Protection Act of 1973, as amended, flood insurance in the amount required above. The proceeds of sale of the REO Property shall be promptly deposited in the Custodial Account. As soon as practical thereafter the expenses of such sale shall be paid and the Special Servicer shall reimburse itself for any related unreimbursed Servicing Advances, unpaid Servicing Fees, unreimbursed Monthly Advances made pursuant to this Section or Section 4.03 or the REO Disposition Fee. The Special Servicer shall make advances of all funds necessary for the proper operation, management and maintenance of the REO Property, including the cost of maintaining any hazard insurance pursuant to Section 3.10, such advances to be reimbursed from the disposition or liquidation proceeds of the REO Property. The Special Servicer shall make monthly distributions on each Remittance Date to the Master Servicer of the net cash flow from the REO Property (which shall equal the revenues from such REO Property net of the expenses described in this Section 3.17 and of any reserves reasonably required from time to time to be maintained to satisfy anticipated liabilities for such expenses).

  • Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.

  • Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity 1.1.02 Identify at least one individual to act as the program contact in the following areas: 1. Immunization Program Manager;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!