RIGHT OF THE CITY TO DECLARE CONTRACTOR IN DEFAULT Sample Clauses

RIGHT OF THE CITY TO DECLARE CONTRACTOR IN DEFAULT. In addition to those instances specifically referred to in the Contract Documents, the City shall have the right to declare Contractor in default of the whole or any part of the Work if: 1) Contractor becomes insolvent; 2) Contractor makes an assignment for the benefit of creditors pursuant to the Statutes of the State of Minnesota; 3) A voluntary or involuntary petition in bankruptcy be filed by or against Contractor; 4) Contractor fails to commence work when notified to do so by the Engineer; 5) Contractor shall abandon the Work; 6) Contractor shall refuse to proceed with the Work when and as directed by the Engineer; 7) Contractor shall, without just cause, reduce his working force to a number which, if maintained would be insufficient, in the opinion of the Engineer, to complete the Work in accordance with the approved progress schedule, and shall fail or refuse to sufficiently increase such working force when ordered to so by the Engineer; 8) Contractor shall sublet, assign, transfer, convey or otherwise dispose of this Contract other than as herein specified; 9) A receiver or receivers are appointed to take charge of Contractor's property or affairs; 10) The Engineer shall be of the opinion that Contractor is or has been knowingly, willfully or in bad faith, violating any of the provisions of this Contract; 11) The Engineer shall be of the opinion that Contractor is or has been unnecessarily, unreasonable or willfully delaying the performance and completion of the Work, or the award of a necessary subcontract or the placing of necessary material or equipment orders; 12) The Engineer shall be of the opinion that the Work cannot be completed within the Contract Time, taking into consideration all agreed upon amendments to the Contract Time; provided, however, that the impossibility of timely completion is, in the Engineer's opinion, attributable to conditions within Contractor's control; 13) The Engineer shall be of the opinion that Contractor is not or has not been executing the Contract in good faith and in accordance with its terms; or 14) The Work is not completed within the Contract Time, taking into consideration all agreed upon amendments to the Contract Time. Before the City shall exercise its right to declare Contractor in default by reason of the conditions set forth in items numbered 1, 4-7, 10-13, or 14, it shall give Contractor an opportunity to be heard, on two days’ notice, at which hearing Contractor may have a stenographer present; pro...
AutoNDA by SimpleDocs

Related to RIGHT OF THE CITY TO DECLARE CONTRACTOR IN DEFAULT

  • Remedies; Obtaining the Collateral Upon Default Each Assignor agrees that, if any Event of Default shall have occurred and be continuing, then and in every such case, the Collateral Agent, in addition to any rights now or hereafter existing under applicable law, shall have all rights as a secured creditor under the Uniform Commercial Code in all relevant jurisdictions and may: (i) personally, or by agents or attorneys, immediately take possession of the Collateral or any part thereof, from such Assignor or any other Person who then has possession of any part thereof with or without notice or process of law, and for that purpose may enter upon such Assignor's premises where any of the Collateral is located and remove the same and use in connection with such removal any and all services, supplies, aids and other facilities of such Assignor; (ii) instruct the obligor or obligors on any agreement, instrument or other obligation (including, without limitation, the Receivables and the Contracts) constituting the Collateral to make any payment required by the terms of such agreement, instrument or other obligation directly to the Collateral Agent; (iii) withdraw all monies, securities and instruments in the Cash Collateral Account for application to the Obligations in accordance with Section 7.4 hereof; (iv) sell, assign or otherwise liquidate any or all of the Collateral or any part thereof in accordance with Section 7.2 hereof, or direct the relevant Assignor to sell, assign or otherwise liquidate any or all of the Collateral or any part thereof, and, in each case, take possession of the proceeds of any such sale or liquidation; (v) take possession of the Collateral or any part thereof, by directing the relevant Assignor in writing to deliver the same to the Collateral Agent at any place or places designated by the Collateral Agent, in which event such Assignor shall at its own expense:

  • RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.

  • Waiver of Master Servicer Events of Default Subject to Section 11.09(d), the Holders representing at least 66% of the Voting Rights evidenced by all Classes of Certificates affected by any default or Master Servicer Event of Default hereunder may waive such default or Master Servicer Event of Default; provided, however, that a default or Master Servicer Event of Default under clause (i) or (vi) of Section 7.01 may be waived only by all of the Holders of the Regular Certificates. Upon any such waiver of a default or Master Servicer Event of Default, such default or Master Servicer Event of Default shall cease to exist and shall be deemed to have been remedied for every purpose hereunder. No such waiver shall extend to any subsequent or other default or Master Servicer Event of Default or impair any right consequent thereon except to the extent expressly so waived.

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • Action upon Certain Failures of the Servicer and upon Event of Default In the event that the Trustee shall have actual knowledge of any failure of the Servicer specified in Section 8.01(a) or (b) which would become an Event of Default upon the Servicer's failure to remedy the same after notice, the Trustee shall give notice thereof to the Servicer. If the Trustee shall have knowledge of an Event of Default, the Trustee shall give prompt written notice thereof to the Certificateholders.

  • Action by Owners with Respect to Bankruptcy The Owner Trustee shall not have the power to commence a voluntary proceeding in bankruptcy relating to the Trust without the unanimous prior approval of all Owners and the delivery to the Owner Trustee by each such Owner of a certificate certifying that such Owner reasonably believes that the Trust is insolvent.

  • Waiver of Events of Default The Holders representing at least 66% of the Voting Rights affected by a default or Event of Default hereunder may waive such default or Event of Default; provided, however, that (a) a default or Event of Default under clause (i) of Section 7.01 may be waived only by all of the Holders of Certificates affected by such default or Event of Default and (b) no waiver pursuant to this Section 7.04 shall affect the Holders of Certificates in the manner set forth in Section 11.01(b)(i) or (ii). Upon any such waiver of a default or Event of Default by the Holders representing the requisite percentage of Voting Rights affected by such default or Event of Default, such default or Event of Default shall cease to exist and shall be deemed to have been remedied for every purpose hereunder. No such waiver shall extend to any subsequent or other default or Event of Default or impair any right consequent thereon except to the extent expressly so waived.

  • Waiver of Servicer Events of Default The Holders representing at least 66% of the Voting Rights evidenced by all Classes of Certificates affected by any default or Servicer Event of Default hereunder may waive such default or Servicer Event of Default; provided, however, that a default or Servicer Event of Default under clause (i) or (vii) of Section 7.01 may be waived only by all of the Holders of the Regular Certificates. Upon any such waiver of a default or Servicer Event of Default, such default or Servicer Event of Default shall cease to exist and shall be deemed to have been remedied for every purpose hereunder. No such waiver shall extend to any subsequent or other default or Servicer Event of Default or impair any right consequent thereon except to the extent expressly so waived.

  • Events of Default Rights and Remedies on Default 10.1 Events of Default 10.2 Acceleration of the Obligations

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!