Demise and Term A. For and during the term established below, Sublessor leases to Subtenant the Demised Premises, consisting of 362,155 rentable square feet ("RSF of the Demised Premises") of space at the Building. The leasing of the Demised Premises by Subtenant shall include the right of Subtenant (a) to access the Building common areas in common with the other tenants in the Building and (b) to use all fixtures, improvements and 2 betterments owned or leased by Overlandlord which, at any time during the term of this Sublease, are attached to or installed in the Demised Premises, all subject to such restrictions, rules, regulations, security arrangements and charges (if any) as are provided for in the Ovexxxxxx.
B. The term (subject to extension as provided herein, the "Term") of this Sublease shall commence on May 19, 2001 (the "Commencement Date ") and expire on November 17, 2021 (the "Expiration Date"), unless sooner canceled or otherwise terminated as provided in this Sublease.
C. Sublessor shall have a one time right to cancel this Sublease effective as of May 31, 2011 by giving written notice (the "Sublessor Cancellation Notice") to Subtenant by no later than May 1, 2008, time being of the essence as to the giving of such notice, which notice shall state that Sublessor unconditionally elects to cancel this Sublease effective as of May 31, 2011. In the event Sublessor fails to timely deliver a Sublessor Cancellation Notice in compliance herewith, and unless Subtenant has delivered the Subtenant Cancellation Notice (as hereinafter defined), this Sublease shall continue until the Expiration Date, unless otherwise terminated as provided in this Sublease. In the event Sublessor timely delivers a Sublessor Cancellation Notice in compliance herewith, the Expiration Date as defined herein shall for all purposes mean May 31, 2011.
D. Subtenant shall have a one time right to cancel this Sublease effective as of May 31, 2011 by giving written notice (the "Subtenant Cancellation Notice") to Sublessor by no later than April 1, 2008, time being of the essence as to the giving of such notice, which notice shall state that Subtenant unconditionally elects to cancel this Sublease effective as of May 31, 2011. In the event Subtenant fails to timely deliver a Subtenant Cancellation Notice in compliance herewith, and unless Sublessor has delivered the Sublessor Cancellation Notice, this Sublease shall continue until the Expiration Date, unless otherwise terminated as provided in this Sublease. In the event Subtenant timely delivers a Subtenant Cancellation Notice in compliance herewith, the Expiration Date as defined herein shall for all purposes mean May 31, 2011.
E. In the event that Sublessor cancels this Sublease pursuant to Article 2.C hereof, Sublessor shall pay to Subtenant, by no later than June 30, 2011, an amount (the "Sales Price") equal to twenty-five percent (25%) of the unamortized value (as of May 31, 2011) of the leasehold improvements (the "Remaining Leasehold Improvements") which remain in the Demised Premises following Subtenant's vacation of the Demised Premises
Price and Terms of Payment To be valid, Supplier's invoices must contain Twitter's Order number and part number, the manufacturer's part number, a full description of the Deliverables, the quantity, unit price and total price, and the delivery address, as applicable. Valid Supplier invoices will become due for payment by Twitter, net thirty (30) days from Twitter's receipt of the Deliverables or the date of receipt of a correct invoice (whichever is later) unless otherwise indicated on the face of the Order. The date of invoice will not predate the date of delivery of the relevant Deliverables. Supplier will send invoices to Twitter's address designated on the face of the Order or to such other address as Twitter may specify in writing. Notwithstanding anything to the contrary contained in the Agreement, (a) Invoices submitted more than six (6) months after Twitter’s receipt of Deliverables will be rejected and no payment shall be made and (b) Twitter shall have no liability whatsoever under the Agreement for amounts due under any such invoice. Currency shall be in United States dollars unless otherwise identified on the face of the Order.
Purchase Price and Terms of Payment The purchase price (“Purchase Price”) for the Interests is SIXTY FIVE MILLION ONE HUNDRED FIFTY THOUSAND AND NO/100 DOLLARS ($65,150,000.00); provided, however, under certain circumstances, as set forth in Section 3(b) hereof, the Purchase Price is subject to be increased based upon the cost to defease all or a part of the Indebtedness. The Purchase Price shall be paid by Buyer as follows:
A. Within three (3) business days after the Effective Date, Buyer shall deposit the sum of FIVE HUNDRED THOUSAND AND NO/100 DOLLARS ($500,000.00) with the Escrow Agent and the Escrow Agent shall deposit the Xxxxxxx Money (hereinafter defined) in an interest bearing account. Buyer shall be entitled to all interest accumulating on the Xxxxxxx Money, unless Seller is entitled to retain the Xxxxxxx Money as liquidated damages pursuant to the terms of Section 14 below. The initial $500,000 deposit together with interest on all such amounts shall hereinafter collectively be called the “Xxxxxxx Money.” Buyer’s taxpayer identification number is 00-0000000.
B. Upon Closing and subject to the provisions of Section 3(b) hereof, the Indebtedness shall not be discharged or released (whether by pay off or defeasance, as applicable), but shall remain outstanding after Closing and the Buyer shall assume such Indebtedness. The Indebtedness, and all documents executed in connection therewith, is listed on Schedule 6 attached hereto and made a part hereof (hereinafter, the “Loan Documents”).
C. Upon Closing, the Xxxxxxx Money shall be applied against the Purchase Price, and the balance of the Purchase Price (subject to the adjustments set forth in paragraph D below) shall be paid to Seller by wire transfer of immediately available funds pursuant to written instructions from Seller. If this Agreement is terminated pursuant the provisions hereof and Buyer is not in default under this Agreement, then Buyer shall be entitled to a return of the Xxxxxxx Money.
D. The amount of cash payable at Closing shall be equal to the amount of the Purchase Price less the amount of Indebtedness (principal and interest) actually assumed by Buyer at Closing (and not defeased) and for which the Companies are released from liability. Seller acknowledges and agrees that: (a) the Exploration Indebtedness will have an outstanding principal balance of approximately $3,444,276.00 as of December 31, 2003, a fixed interest rate of 8.6251% and a maturity date of June 26, 2009; (b) the Exploration III Indebtedness will have an outstanding principal balance of approximately $3,057,761.00 as of December 31, 2003, a fixed interest rate of 8.75% and a maturity date of August 1, 2007; and (c) the Red Cedar Indebtedness will have an outstanding principal balance of approximately $4,104,082.00 as of December 31,2003, a fixed interest rate of 7.7% and a maturity date of November 1, 2007.
E. Notwithstanding any contrary provision contained herein, the Purchase Price shall also be increased at Closing by an amount equal to the total amount of all escrow amounts held by the holder or holders of all Loans assumed by Buyer at Closing, including, without limitation, escrows for taxes, insurance, leasing upfit costs and leasing commissions.
Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project.
b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent.
c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect.
g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord.
l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease.
n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Issuance and Terms of Equipment Notes The Equipment Notes shall be dated the date of issuance thereof, shall be issued in three separate series consisting of Series A, Series B and Series C and in the maturities and principal amounts and shall bear interest as specified in Schedule I hereto. On the date of the consummation of the Transactions, each Equipment Note shall be issued to the Subordination Agent on behalf of the Pass Through Trustees under the Pass Through Trust Agreements. The Equipment Notes shall be issued in registered form only. The Equipment Notes shall be issued in denominations of $1,000 and integral multiples thereof, except that one Equipment Note of each Series may be in an amount that is not an integral multiple of $1,000. Each Equipment Note shall bear interest at the Debt Rate (calculated on the basis of a year of 360 days comprised of twelve 30-day months) on the unpaid Original Amount thereof from time to time outstanding, payable in arrears on April 1, 1998, and on each October 1 and April 1 thereafter until maturity. The Original Amount of each Equipment Note shall be payable on the dates and in the installments equal to the corresponding percentage of the Original Amount as set forth in Schedule I hereto which shall be attached as Schedule I to the Equipment Notes. Notwithstanding the foregoing, the final payment made under each Equipment Note shall be in an amount sufficient to discharge in full the unpaid Original Amount and all accrued and unpaid interest on, and any other amounts due under, such Equipment Note. Each Equipment Note shall bear interest at the Payment Due Rate (calculated on the basis of a year of 360 days comprised of twelve 30-day months) on any part of the Original Amount, Make-Whole Amount, if any, and, to the extent permitted by applicable Law, interest and any other amounts payable thereunder not paid when due for any period during which the same shall be overdue, in each case for the period the same is overdue. Amounts shall be overdue if not paid when due (whether at stated maturity, by acceleration or otherwise). Notwithstanding anything to the contrary contained herein, if any date on which a payment under any Equipment Note becomes due and payable is not a Business Day then such payment shall not be made on such scheduled date but shall be made on the next succeeding Business Day and if such payment is made on such next succeeding Business Day, no interest shall accrue on the amount of such payment during such extension.
Alteration to terms of insurances No Borrower shall make or agree to any alteration to the terms of any obligatory insurance or waive any right relating to any obligatory insurance.
PRICE AND TERMS The Purchase Price set forth below is payable in U.S. Dollars by Buyer as follows: 1 § 4.1 Purchase Price $ 2 § 4.3 Xxxxxxx Money $ 3 § 4.5 New Loan $ 4 § 4.6 Assumption Balance $ 5 § 4.7 Private Financing $ 6 § 4.7 Seller Financing $ 9 § 4.4 Cash at Closing $ 10 TOTAL $ $
Lease Terms 8.1. The Tenant must observe and perform all conditions and covenants that apply to the Allotment Site contained in any lease under which the Council hold the Allotment Site.
Access to Work District representatives shall at all times have access to the Work, wherever it is, in preparation or in progress. Contractor shall provide safe and proper facilities for such access.
Option to Extend Term Tenant shall have the option (“Option”) to extend the Term by five (5) years as to the entire Premises (and no less than the entire Premises) upon the following terms and conditions. Any extension of the Term pursuant to the Option shall be on all the same terms and conditions as this Lease, except as follows:
42.1. Base Rent during the Option term (including annual escalations, if applicable) shall equal the then-current fair market value for comparable office and laboratory space in the Xxxxxx Xxxxx submarket of comparable age, quality, level of finish and proximity to amenities and public transit (“FMV”). Tenant may, no more than twelve (12) months prior to the date the Term is then scheduled to expire, request Landlord’s estimate of the FMV for the Option term. Landlord shall, within fifteen (15) days after receipt of such request, give Tenant a written proposal of such FMV. If Tenant gives written notice to exercise the Option, such notice shall specify whether Tenant accepts Landlord’s proposed estimate of FMV. If Tenant does not accept the FMV, then the parties shall endeavor to agree upon the FMV, taking into account all relevant factors, including (a) the size of the Premises, (b) the length of the Option term, (c) rent in comparable buildings in the relevant submarket, including concessions offered to new tenants, such as free rent, tenant improvement allowances and moving allowances, (d) Tenant’s creditworthiness and (e) the quality and location of the Building and the Project. In the event that the parties are unable to agree upon the FMV within thirty (30) days after Tenant notifies Landlord that Tenant is exercising the Option, then either party may request that the same be determined as follows: a senior officer of a nationally recognized leasing brokerage firm with local knowledge of the Xxxxxx Xxxxx laboratory/research and development leasing submarket (the “Baseball Arbitrator”) shall be selected and paid for jointly by Landlord and Tenant. If Landlord and Tenant are unable to agree upon the Baseball Arbitrator, then the same shall be designated by the local chapter of the American Arbitration Association or any successor organization thereto (the “AAA”). The Baseball Arbitrator selected by the parties or designated by the AAA shall (y) have at least ten (10) years’ experience in the leasing of laboratory/research and development space in the Xxxxxx Xxxxx submarket and (z) not have been employed or retained by either Landlord or Tenant or any affiliate of either for a period of at least ten (10) years prior to appointment pursuant hereto. Each of Landlord and Tenant shall submit to the Baseball Arbitrator and to the other party its determination of the FMV. The Baseball Arbitrator shall grant to Landlord and Tenant a hearing and the right to submit evidence. The Baseball Arbitrator shall determine which of the two (2) FMV determinations more closely represents the actual FMV. The arbitrator may not select any other FMV for the Premises other than one submitted by Landlord or Tenant. The FMV selected by the Baseball Arbitrator shall be binding upon Landlord and Tenant and shall serve as the basis for determination of Base Rent payable for the Option term. If, as of the commencement date of the Option term, the amount of Base Rent payable during the Option term shall not have been determined, then, pending such determination, Tenant shall pay Base Rent equal to the Base Rent payable with respect to the last year of the then-current Term. After the final determination of Base Rent payable for the Option term, the parties shall promptly execute a written amendment to this Lease specifying the amount of Base Rent to be paid during the Option term. Any failure of the parties to execute such amendment shall not affect the validity of the FMV determined pursuant to this Section.
42.2. The Option is not assignable separate and apart from this Lease.
42.3. The Option is conditional upon Tenant giving Landlord written notice of its election to exercise the Option on or before the date that is nine (9) months prior to the expiration of the then-current Term (such date, the “Option Date”). Time shall be of the essence as to Tenant’s exercise of the Option. Tenant assumes full responsibility for maintaining a record of the deadlines to exercise the Option. Tenant acknowledges that it would be inequitable to require Landlord to accept any exercise of the Option after the date provided for in this Section.
42.4. Notwithstanding anything contained in this Article to the contrary, Tenant shall not have the right to exercise the Option:
(a) During the time commencing from the date Landlord delivers to Tenant a written notice that Tenant is in default under any provisions of this Lease and continuing until Tenant has cured the specified default to Landlord’s reasonable satisfaction; or
(b) At any time after any Default as described in Article 31 of the Lease and continuing until Tenant cures any such Default, if such Default is susceptible to being cured; or
(c) In the event that Tenant has defaulted in the performance of its obligations under this Lease two (2) or more times and a service or late charge has become payable under Section 31.1 for each of such defaults during the twelve (12)-month period immediately prior to the date that Tenant intends to exercise the Option, whether or not Tenant has cured such defaults.
42.5. The period of time within which Tenant may exercise the Option shall not be extended or enlarged by reason of Tenant’s inability to exercise such Option because of the provisions of Section 42.4.
42.6. All of Tenant’s rights under the provisions of the Option shall terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Option if, after such exercise, but prior to the commencement date of the new term, (a) Tenant fails to pay to Landlord a monetary obligation of Tenant for a period of twenty (20) days after written notice from Landlord to Tenant, (b) Tenant fails to commence to cure a default (other than a monetary default) within thirty (30) days after the date Landlord gives notice to Tenant of such default or (c) Tenant has defaulted under this Lease two (2) or more times and a service or late charge under Section 31.1 has become payable for any such default, whether or not Tenant has cured such defaults.
