Scope of Excusable Delay Sample Clauses

Scope of Excusable Delay. Neither the Seller nor any Affiliate of the Seller, will be responsible for or be deemed to be in default on account of delays in delivery or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller’s, or any Affiliate’s control or not occasioned by the Seller’s, fault or negligence (“Excusable Delay”), including, but not limited to: (i) acts of God or the public enemy, natural disasters, fires, floods, storms beyond ordinary strength, explosions or earthquakes; epidemics or quarantine restrictions; serious accidents; total or constructive total loss; any law, decision, regulation, directive or other act (whether or not having the force of law) of any government or of the Council of the European Community or the Commission of the European Community or of any national, Federal, State, municipal or other governmental department, commission, board, bureau, agency, court or instrumentality, domestic or foreign; governmental priorities, regulations or orders affecting allocation of materials, facilities or a completed Aircraft; war, civil war or warlike operations, terrorism, insurrection or riots; failure of transportation; strikes or labor troubles causing cessation, slow down or interruption of work; delay in obtaining any airworthiness or type certification; inability after due and timely diligence to procure materials, accessories, equipment or parts; general hindrance in transportation; or failure of a subcontractor or Supplier to furnish materials, components, accessories, equipment or parts; (ii) any delay caused directly or indirectly by the action or inaction of the Buyer; and (iii) delay in delivery or otherwise in the performance of this Agreement by the Seller due in whole or in part to any delay in or failure of the delivery of, or any other event or circumstance relating to, the Propulsion Systems or Buyer Furnished Equipment.
Sample 1Sample 2Sample 3See All (24)
AutoNDA by SimpleDocs
Scope of Excusable Delay. Neither the Seller nor any Affiliate of the Seller, will be responsible for or be deemed to be in default on account of delays in delivery of the Aircraft or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes beyond the Seller’s, or any Affiliate’s control or not occasioned by the Seller’s, fault or negligence (“Excusable Delay”), including, but not limited to: *****.
Sample 1Sample 2Sample 3See All (5)
Scope of Excusable Delay. Neither the Seller nor any Affiliate of the Seller, will be responsible for or be deemed to be in default on account of delays in delivery or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller’s control or not occasioned by the Seller’s fault or negligence (“Excusable Delay”), including, but not limited to: (i) acts of God or the public enemy, natural disasters, fires, floods, storms beyond ordinary strength, explosions or earthquakes; epidemics or quarantine restrictions; serious accidents; total or constructive total loss; any law, decision, regulation, directive or other act (whether or not having the force of law) of any government or of the Council of the European Union or the Commission of the European Union or of any national, Federal, State, municipal or other governmental department, commission, board, bureau, agency, court or instrumentality, domestic or foreign; governmental priorities, regulations or orders affecting allocation of materials, facilities or a completed Aircraft; war, civil war or warlike operations, terrorism, insurrection or riots; failure of transportation ** strikes or labor troubles causing cessation, slow down or interruption of work; inability after due and timely diligence to procure materials, accessories, equipment or parts or to cause a subcontractor or Supplier to furnish materials, components, accessories, equipment or parts; **(iii) any delay caused directly or indirectly by the action or inaction of the Buyer, and (iv) delay in delivery or otherwise in the performance of this Agreement by the Seller due in whole or in part to any delay in or failure of the delivery of, or any other event or circumstance relating to **BFE.
Sample 1See All (4)
Scope of Excusable Delay. Neither the Seller, the Manufacturer, the Associated Contractors, nor any Affiliate of any of the foregoing, will be responsible for or be deemed to be in default on account of delays in delivery or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller's, the Manufacturer's or any Associated Contractor's control or not occasioned by the Seller's, the Manufacturer's or any Associated Contractor's fault or negligence ("EXCUSABLE DELAY"), including, but not limited to: (i) acts of God or the public enemy, natural disasters, fires, floods, storms beyond ordinary strength, explosions or earthquakes; epidemics or quarantine restrictions; serious accidents; total or constructive total loss; any law, decision, regulation, directive or other act (whether or not having the force of law) of any government or of the Council of the European Union or the Commission of the European Union or of any national, Federal, State, municipal or other governmental department, commission, board, bureau, agency, court or instrumentality, domestic or foreign; governmental priorities, regulations or orders affecting allocation of materials, facilities or a completed Aircraft; war, civil war or warlike operations, terrorism, insurrection or riots; failure of transportation; strikes or labor troubles causing cessation, slow down or interruption of work; inability after due and timely diligence to procure materials, accessories, equipment or parts or to cause a subcontractor or Supplier to furnish materials, components, accessories, equipment or parts; general hindrance in transportation; (ii) [...***...]; and (iii) any delay caused directly or indirectly by the action or inaction of any Buyer.
Sample 1
Scope of Excusable Delay. Neither the Seller, the Manufacturer, the Associated Contractors, nor any Affiliate of any of the foregoing, will be responsible for or be deemed to be in default on account of delays in delivery of or failure to deliver an Aircraft or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller's, the Manufacturer's or any Associated Contractor's control or not occasioned by the Seller's, the Manufacturer's or any Associated Contractor's fault or negligence ("Excusable Delay"), including, but not limited to: (i) acts of God or the public enemy, natural disasters, fires, floods, storms beyond ordinary strength, explosions or earthquakes; epidemics or quarantine restrictions; serious accidents; total or constructive total loss; any law, decision, regulation, directive or other act (whether or not having the force of law but if not having the force of law, with which similar entities generally comply) of any government or of the Council of the European Community or the Commission of the European Community or of any national, Federal, State, municipal or other governmental department, commission, board, bureau, agency, court or instrumentality, domestic or foreign; governmental priorities, regulations or orders affecting allocation of materials, facilities or a completed Aircraft; war, civil war or warlike operations, terrorism, insurrection or riots; failure of transportation; strikes or labor troubles causing cessation, slow down or interruption of work; delay in obtaining any airworthiness or type certification; inability after due and timely diligence to procure materials, accessories, equipment or parts; [***]. Spirit Airlines - A320 Family Aircraft LA11-7
Sample 1
Scope of Excusable Delay. Neither the Seller nor any Affiliate of the Seller will be responsible for or be deemed to be in default on account of delays in delivery or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller’s control or not occasioned by the Seller’s fault or negligence (“Excusable Delay”), including, but not limited to: (i) [*CTR]; (ii) [*CTR]; (iii) [*CTR]; and (iv) [*CTR]. UNQUOTE
Sample 1
Scope of Excusable Delay. Neither the Seller nor any Affiliate of the Seller will be responsible for or be deemed to be in default on account of delays in delivery or failure to deliver or otherwise in the performance of this Agreement or any part hereof due to causes reasonably beyond the Seller’s control or not occasioned by the Seller’s fault or negligence (“Excusable Delay”), including, but not limited to: (i) *****; (ii) *****; (iii) *****; and (iv) *****. ***** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE COMMISSION PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT. USA – Second Amended and Restated Letter Agreement No. 9 to Amended and Restated Airbus A350 XWB Purchase Agreement EXECUTION PRIVILEGED AND CONFIDENTIAL UNQUOTE
Sample 1
AutoNDA by SimpleDocs

Related to Scope of Excusable Delay

  • Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • FORCE MAJEURE CLAUSE Contractor shall be excused from performance hereunder during the time and to the extent that it is prevented from obtaining delivery, or performing by act of God, fire, strike, loss, or shortage of transportation facilities, lock-out, commandeering of materials, product, plant, or facilities by the government, when satisfactory evidence thereof is presented to the District, provided that it is satisfactorily established that the

  • Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

  • Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!