Interconnection Customer Obligations The Interconnection Customer shall maintain the Large Generating Facility and the Interconnection Customer’s Interconnection Facilities in a safe and reliable manner and in accordance with this LGIA.
Warranty Obligations
(a) Project Co represents, warrants and covenants that:
(i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario;
(ii) the Works shall be free of defects, including design defects, errors and omissions; and
(iii) materials and equipment shall be of good quality and in compliance with this Project Agreement.
(b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole.
(c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario).
(d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment.
(e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense.
(f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Diligence Obligations (a) Subject to Section 2.5(b) below, Proprius agrees to use commercially reasonable efforts (directly and/or through one or more Affiliates and Sublicenses) to bring one or more initial Products to market in the Field in the Territory and, following first commercial sale, to promote such Initial Product(s) in the Field in the Territory during the Term. Without limiting the generality of the foregoing (but subject to Section 2.5(b)), Proprius shall achieve first commercial sale of an Initial Product by December 31, 2008. If, despite its commercially reasonable efforts, Proprius fails to achieve first commercial sale of an Initial Product by December 31, 2008, the parties shall discuss in good faith an appropriate extension of such deadline and/or other modification of such diligence milestone. If the parties are unable to reach mutual agreement on such extension or modification, ORGENTEC shall have the right to convert Proprius’ license under Section 2.1 to a co-exclusive license upon written notice to Proprius.
(b) Proprius’ diligence obligations under Section 2.5(a) are subject to ORGENTEC using commercially reasonable efforts to obtain U.S. Food and Drug Administration clearance or approval of its Anti-MCV (autoantibodies against mutated citrullinated vimentin) E XXXX technology by December 31, 2009. Proprius shall, if available and to the extent permitted by applicable laws and commercially reasonable, the protocols approved by the respective IRBs/ Ethic Committees of the institutions through which samples were collected, and any informed consents obtained by Proprius from sample donors, transfer (or cause to be transferred) available patient samples to ORGENTEC to support the FDA approval process. Proprius hereby grants to ORGENTEC, to the extent permitted by applicable laws a non-exclusive license, to use the transferred samples for FDA approval purposes for Initial Products or Additional Products In the Field in the Territory. Should ORGENTEC not act diligently to achieve the FDA approval before or no later then December 31, 2009, Proprius has the right, at its own discretion, to solely oversee and manage the FDA approval. In such case ORGENTEC would continue to carry the costs for the FDA approval process.
Maintenance Obligations Local Agency shall maintain and operate the Work constructed under this Agreement at its own cost and expense during their useful life, in a manner satisfactory to the State and FHWA. Local Agency shall conduct such maintenance and operations in accordance with all applicable statutes, ordinances, and regulations pertaining to maintaining such improvements. The State and FHWA may make periodic inspections to verify that such improvements are being adequately maintained.
Bidder Supplied Samples The Commissioner reserves the right to request from the Bidder/Contractor a representative sample(s) of the Product offered at any time prior to or after award of a contract. Unless otherwise instructed, samples shall be furnished within the time specified in the request. Untimely submission of a sample may constitute grounds for rejection of Bid or cancellation of the Contract. Samples must be submitted free of charge and be accompanied by the Bidder’s name and address, any descriptive literature relating to the Product and a statement indicating how and where the sample is to be returned. Where applicable, samples must be properly labeled with the appropriate Bid or Contract reference. A sample may be held by the Commissioner during the entire term of the Contract and for a reasonable period thereafter for comparison with deliveries. At the conclusion of the holding period the sample, where feasible, will be returned as instructed by the Bidder, at the Bidder’s expense and risk. Where the Bidder has failed to fully instruct the Commissioner as to the return of the sample (i.e., mode and place of return, etc.) or refuses to bear the cost of its return, the sample shall become the sole property of the receiving entity at the conclusion of the holding period.
Supplier Obligations 7.1 The Supplier shall:
7.1.1 at all times allocate sufficient resources to supply the Services in accordance with the Contract;
7.1.2 provide and fulfil any ancillary or incidental service, function or responsibility not specified in the Service Specification where such service, function or responsibility is necessary for the proper performance of the relevant Services;
7.1.3 obtain, and maintain throughout the duration of the Contract, all the consents, approvals, licences and permissions (statutory, regulatory, contractual or otherwise) it may require and which are necessary for the provision of the Services or performance of any other obligation under this Contract;
7.1.4 ensure the Supplier Assets used in the performance of the Services will be free of all encumbrances (except as agreed in writing with the Authority);
7.1.5 ensure that in the performance of its obligations under the Contract it does not disrupt the operations of each Commissioning Body and their respective Personnel;
7.1.6 ensure that any documentation, information and training provided to each Commissioning Body under this Contract (including in relation to the use of the Website) is comprehensive, accurate and prepared in accordance with Good Industry Practice;
7.1.7 co-operate with the Other Supplier(s) and provide reasonable information (including any documentation), advice and assistance in connection with the Services to the Other Supplier(s) including to enable such Other Supplier(s) to provide services to the respective Commissioning Bodies and, on the expiry or termination of this Contract for any reason, to enable the timely transition of the Services (or any of them) to the respective Commissioning Bodies and/or to any Replacement Supplier;
7.1.8 to the extent it is legally able to do so, hold on trust for the sole benefit of the Authority, all warranties and indemnities provided by third parties or any Sub- contractor in respect of any Deliverables and/or the Services and, where any such warranties are held on trust, at its cost enforce such warranties in accordance with any reasonable directions that the Authority may notify from time to time to the Supplier;
7.1.9 unless it is unable to do so, assign to the Authority on the Authority’s written request and at the cost of the Supplier any such warranties and/or indemnities as are referred to in Clause 7.1.8;
7.1.10 provide each Commissioning Body with such advice and assistance as that Commissioning Body may reasonably require during the Contract Period in respect of the supply of the Services;
7.1.11 gather, collate and provide such information and co-operation as the Authority may reasonably request for the purposes of ascertaining the Supplier’s compliance with its obligations under the Contract;
7.1.12 notify the Authority of any circumstances suggesting that a change of Control of the Supplier is planned, in contemplation or has taken place;
7.1.13 notify the Authority in writing of any material detrimental change in the financial standing and/or any change in the credit rating of the Supplier;
7.1.14 subject to Clause 33.6, notify the Authority in writing within ten (10) Working Days of their occurrence, of any actions, suits or proceedings or regulatory investigations before any court or administrative body or arbitration tribunal pending or, to its knowledge, threatened against it that might affect its ability to perform its obligations under the Contract; and
7.1.15 ensure that neither it, nor any of its Affiliates or Personnel, bring any Commissioning Body into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in that Commissioning Body, regardless of whether or not such act or omission is related to the Supplier’s obligations under this Contract.
Repair Obligation If neither party elects to terminate this Lease following a Casualty, then Landlord shall, within a reasonable time after such Casualty, begin to repair the Premises and shall proceed with reasonable diligence to restore the Premises to substantially the same condition as they existed immediately before such Casualty; however, other than building standard leasehold improvements Landlord shall not be required to repair or replace any Alterations or betterments within the Premises (which shall be promptly and with due diligence repaired and restored by Tenant at Tenant’s sole cost and expense) or any furniture, equipment, trade fixtures or personal property of Tenant or others in the Premises or the Building, and Landlord’s obligation to repair or restore the Premises shall be limited to the extent of the insurance proceeds actually received by Landlord for the Casualty in question. If this Lease is terminated under the provisions of this Section 15, Landlord shall be entitled to the full proceeds of the insurance policies providing coverage for all Alterations, improvements and betterments in the Premises (and, if Tenant has failed to maintain insurance on such items as required by this Lease, Tenant shall pay Landlord an amount equal to the proceeds Landlord would have received had Tenant maintained insurance on such items as required by this Lease).
QUANTITY BASIS OF CONTRACT – NO GUARANTEED QUANTITIES The contract established has no guarantee of any specific quantity and the State is obligated only to buy that quantity which is needed by its agencies.
Interconnection Customer’s Interconnection Facilities The Interconnection Customer shall design, procure, construct, install, own and/or control the Interconnection Customer’s Interconnection Facilities described in Appendix A at its sole expense.
CONTRACTOR OBLIGATION Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records provided to Enterprise Services that Contractor believes are statutorily exempt from disclosure and identify the precise statutory basis for exemption from disclosure. In addition, if, in Contractor’s judgment, certain portions of such records are not statutorily exempt from disclosure but are sensitive because particular portions of Contractor’s records (NOT including pricing) include highly confidential, proprietary, or trade secret information (or the equivalent) that Contractor protects through the regular use of confidentiality or similar agreements and routine enforcements through court enforcement actions, Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records that include such sensitive information.
