SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board.
(2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein.
(3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
Trustee to Sign Amendments, etc The Trustee will sign any amended or supplemental indenture authorized pursuant to this Article 9 if the amendment or supplement does not adversely affect the rights, duties, liabilities or immunities of the Trustee. The Company may not sign an amended or supplemental indenture until the Board of Directors of the Company approves it. In executing any amended or supplemental indenture, the Trustee will be entitled to receive and (subject to Section 7.01 hereof) will be fully protected in relying upon, in addition to the documents required by Section 12.04 hereof, an Officers’ Certificate and an Opinion of Counsel stating that the execution of such amended or supplemental indenture is authorized or permitted by this Indenture.
Trustee to Sign Amendments The Trustee shall sign any amendment authorized pursuant to this Article 9 if the amendment does not adversely affect the rights, duties, liabilities or immunities of the Trustee. If it does, the Trustee may but need not sign it. In signing such amendment the Trustee shall be entitled to receive indemnity reasonably satisfactory to it and to receive, and (subject to Section 7.01) shall be fully protected in relying upon, an Officers' Certificate and an Opinion of Counsel stating that such amendment is authorized or permitted by this Indenture.
Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Schematic Design Phase 1.2.1 Based on the mutually agreed upon Program of Requirements, Amount Available for the Construction Contract and the Project Schedule, the Architect/Engineer shall prepare sufficient alternative approaches utilizing BIM for design and construction of the Project to satisfy Owner’s project requirements and shall, at completion of this phase, submit Schematic Design Documents derived from the model in accordance with the BIM Execution Plan, “Facility Design Guidelines” and any additional requirements set forth in Article 15. The Architect/Engineer shall review alternative approaches to design and construction for the Project as they are being modeled at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by the Owner within the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Schematic Design. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.2.2 Architect/Engineer shall provide all services necessary to perform the services of this phase (preparation of model(s), relevant data, decision support model views and Schematic Design Documents) including, without limitation, unless otherwise approved by Owner, the preparation and prompt delivery of all items specified in the BIM Execution Plan and “Facility Design Guidelines”.
1.2.3 Architect/Engineer shall work closely with Owner in preparation of schematic drawings and shall specifically conform to Owner’s requirements regarding aesthetic design issues.
1.2.4 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.2.5 Before proceeding into the Design Development Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Schematic Design documents and approval of the Architect/Engineer’s preliminary Estimated Construction Cost and schedule.
1.2.6 The Architect/Engineer shall participate in a final review of the Schematic Design Documents and model(s) with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Schematic Design Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments, any of which may be appealed for good cause.
Signs; Exterior Appearance Tenant shall not, without the prior written consent of Landlord, which may be granted or withheld in Landlord’s sole discretion: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens other than Landlord’s standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window xxxxx, (v) place any equipment, furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any type which can be viewed from the exterior of the Premises. Interior signs on doors and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at the sole cost and expense of Tenant, and shall be of a size, color and type acceptable to Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlord’s standard lettering. The directory tablet shall be provided exclusively for the display of the name and location of tenants.
Sign-On Bonus Pursuant to the Prior Agreement, Executive was paid a one-time signing bonus equal to the amount of $50,000, less any taxable withholdings (the “Sign-On Bonus”). If Executive is terminated for Cause or voluntarily leaves the Company without Good Reason prior to completing twenty-four (24) months of service from August 14, 2023, Executive shall be required to repay to the Company, within thirty (30) days following Executive’s last day of employment with the Company, 100% of the Sign-On Bonus.
