Special Events For the purposes of this Agreement, “special events” are defined as:
Additional Event of Suspension Section 4.01. Pursuant to Section 6.02 (l) of the General Conditions, the following additional event is specified, namely, that a situation has arisen which shall make it improbable that the Program, or a significant part thereof, will be carried out.
Political Event A Political Event shall mean one or more of the following acts or events by or on account of any Government Instrumentality:
(a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 37 and its effect, in financial terms, exceeds the sum specified in Clause 37.1;
(b) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Concessionaire or of the Contractors;
(c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Concessionaire or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit;
(d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
(e) any event or circumstance of a nature analogous to any of the foregoing.
Transfer to Avoid Termination Event If either an Illegality under Section 5(b)(i)(1) or a Tax Event occurs and there is only one Affected Party, or if a Tax Event Upon Merger occurs and the Burdened Party is the Affected Party, the Affected Party will, as a condition to its right to designate an Early Termination Date under Section 6(b)(iv), use all reasonable efforts (which will not require such party to incur a loss, excluding immaterial, incidental expenses) to transfer within 20 days after it gives notice under Section 6(b)(i) all its rights and obligations under this Agreement in respect of the Affected Transactions to another of its Offices or Affiliates so that such Termination Event ceases to exist. If the Affected Party is not able to make such a transfer it will give notice to the other party to that effect within such 20 day period, whereupon the other party may effect such a transfer within 30 days after the notice is given under Section 6(b)(i). Any such transfer by a party under this Section 6(b)(ii) will be subject to and conditional upon the prior written consent of the other party, which consent will not be withheld if such other party's policies in effect at such time would permit it to enter into transactions with the transferee on the terms proposed.
Incident Event and Communications Management a. Incident Management/Notification of Breach - DST shall develop, implement and maintain an incident response plan that specifies actions to be taken when DST or one of its subcontractors suspects or detects that a party has gained material unauthorized access to Fund Data or systems or applications containing any Fund Data (the “Response Plan”). Such Response Plan shall include the following:
i. Escalation Procedures - An escalation procedure that includes notification to senior managers and appropriate reporting to regulatory and law enforcement agencies. This procedure shall provide for reporting of incidents that compromise the confidentiality of Fund Data (including backed up data) to Fund via telephone or email (and provide a confirmatory notice in writing as soon as practicable); provided that the foregoing notice obligation is excused for such period of time as DST is prohibited by law, rule, regulation or other governmental authority from notifying Fund.
ii. Incident Reporting - DST will use commercially reasonable efforts to promptly furnish to Fund information that DST has regarding the general circumstances and extent of such unauthorized access to the Fund Data.
Indirect Political Event An Indirect Political Event shall mean one or more of the following acts or events:
(a) an act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or military action, civil commotion or politically motivated sabotage;
(b) industry-wide or State-wide strikes or industrial action for a continuous period of 24 (twenty four) hours and exceeding an aggregate period of 7 (seven) days in an Accounting Year;
(c) any civil commotion, boycott or political agitation which prevents collection of Fee by the Concessionaire for an aggregate period exceeding 7 (seven) days in an Accounting Year;
(d) any failure or delay of a Contractor to the extent caused by any Indirect Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(e) any Indirect Political Event that causes a Non-Political Event; or
(f) any event or circumstances of a nature analogous to any of the foregoing.
Servicer Termination Event For purposes of this Agreement, each of the following shall constitute a “Servicer Termination Event”:
Non-Political Event A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor;
(e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority;
(f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or
(g) any event or circumstances of a nature analogous to any of the foregoing.
Additional Event of Default The following will constitute an additional Event of Default with respect to Party B: "NOTE ACCELERATION NOTICE. A Note Acceleration Notice is served on Party B in relation to the Relevant Notes."
Special Event Redemption Prior to March 30, 2010, upon the occurrence and during the continuation of a Special Event, the Company may, at its option, redeem the Securities, in whole but not in part, at a Redemption Price equal to one hundred seven and one half percent (107.5%) of the principal amount thereof, together, in the case of any such redemption, with accrued interest, including any Additional Interest, through but excluding the date fixed as the Redemption Date (the “Special Redemption Price”).
