Proper Instructions and Special Instructions “Proper Instructions,” which may also be standing instructions, as such term is used throughout this Agreement shall mean instructions received by the Custodian from a Fund, a Fund’s duly authorized investment manager or investment adviser, or a person or entity duly authorized by either of them. Such instructions may be in writing signed by the authorized person or persons or may be in a tested communication or in a communication utilizing access codes effected between electro-mechanical or electronic devices or may be by such other means and utilizing such intermediary systems and utilities as may be agreed from time to time by the Custodian and the person(s) or entity giving such instruction, provided that the Fund has followed any security procedures agreed to from time to time by the applicable Fund and the Custodian including, but not limited to, the security procedures selected by the Fund via the form of Funds Transfer Addendum hereto, the terms of which are hereby agreed to. Oral instructions will be considered Proper Instructions if the Custodian reasonably believes them to have been given by a person authorized to provide such instructions with respect to the transaction involved; the Fund shall cause all oral instructions to be confirmed in writing. For purposes of this Section, Proper Instructions shall include instructions received by the Custodian pursuant to any multi-party agreement which requires a segregated asset account in accordance with Section 2.9 hereof.
Form instructions This form does not mandate the use of a specific font size or style but the font must be legible.
Course Curriculum, Instruction, and Grading X. Xxxx College courses offered as dual credit, regardless of where they are taught, follow the same syllabus, course outline, textbook, grading method, and other academic policies as the courses outlined in the Hill College catalog.
B. Approved courses being taught for dual credit must follow the approved master syllabus of the discipline and of Hill College.
C. Textbooks should be identical to those approved for use by Hill College. Should an instructor propose an alternative textbook, the textbook must be approved in advance by the appropriate instructional department of Hill College and the Vice President of Instruction. Other instructional materials for dual credit/concurrent courses must be identical or at an equivalent level to materials used by Hill College.
D. Courses which result in college‐level credit will follow the standard grading practices of Hill College, as identified by college policy and as identified in the appropriately approved course syllabus. The grades used in college records are A (excellent), B (above average), C (average), D (below average), F (failure), I (incomplete), W (withdrawn), WC (withdrawn COVID). The lowest passing grade is D. Grade point averages are computed by assigning values to each grade as follows: A = 4 points, B = 3 points, C = 2 points, D = 1 point, and F = 0 points. Grading criteria may be devised by Hill College and the ISD to allow faculty the opportunity to award high school credit only or high school and college credit depending upon student performance.
E. Faculty, who are responsible for teaching dual credit/concurrent classes, are responsible for keeping appropriate records, certifying census date rosters, providing interim grade reports, certifying final grade reports at the end of the semester, certifying attendance, and providing other reports and information as may be required by Hill College and/or the School District.
Disbursement Instructions Xxxxxxxx understands that no loan proceeds will be disbursed until all of Xxxxxx’s conditions for making the loan have been satisfied. Please disburse the loan proceeds of $479,984.97 as follows: Other Disbursements: $ 479,984.97 $479,984.97 CURRENT BALANCE AFTER $150,000.00 PRINCIPAL PAYDOWN Note Principal: $ 479,984.97 CHARGES PAID IN CASH. Xxxxxxxx has paid or will pay in cash as agreed the following charges: Prepaid Finance Charges Paid in Cash: $ 0.00 Other Charges Paid in Cash: $ 154,919.90 $1,000.00 LOAN FEE $3,919.90 INTEREST DUE MARCH 3, 2010 $150,000.00 PRINCIPAL PAYDOWN Total Charges Paid in Cash $ 154,919.90 FINANCIAL CONDITION. BY SIGNING THIS AUTHORIZATION, XXXXXX REPRESENTS AND WARRANTS TO THE LENDER THAT THE INFORMATION PROVIDED ABOVE IS TRUE AND CORRECT AND THAT THERE HAS BEEN NO MATERIAL ADVERSE CHANGE IN BORROWER’S FINANCIAL CONDITION AS DISCLOSED IN BORROWER’S MOST RECENT FINANCIAL STATEMENT TO LENDER. THIS AUTHORIZATION IS DATED MARCH 3, 2010 ICOP DIGITAL, INC By: /s/ Xxxxx X. Xxxx XXXXX X. XXXX, Chairman & CEO of ICOP DIGITAL, INC DESCRIPTION OF EXISTING INDEBTEDNESS. PROMISSORY NOTE DATED MARCH 3, 2008 IN THE AMOUNT OF $780,000.00 TOGETHER WITH ANY AND ALL RENEWALS/MODIFICATIONS THEREOF (“NOTE”). DESCRIPTION OF CHANGE IN TERMS. EXTEND THE MATURITY DATE FROM MARCH 3, 2010 TO MARCH 3, 2011; DECREASE CURRENT PRINCIPAL BALANCE FROM $629,985.97 TO $479,984.97. PROMISE TO PAY. ICOP DIGITAL, INC (“Borrower”) promises to pay to Bank of Blue Valley (“lender”), or order, in lawful money of the United States of America, the principal amount of Four Hundred Seventy~nine Thousand Nine Hundred Eighty~four & 97/100 Dollars ($479,984.97), together with interest on the unpaid principal balance from March 3, 2010, calculated as described in the “INTEREST CALCULATION METHOD” paragraph using an interest rate of 8.000% per annum based on a year of 360 days, until paid in full. The interest rate may change under the terms and conditions of the “INTEREST AFTER DEFAULT” section.
Construction Phase Services 3.1.1 – Basic Construction Services
DELIVERY INSTRUCTIONS In the event of a Failed Remarketing, Notes which are in physical form should be delivered to the person(s) set forth below and mailed to the address set forth below. Name(s) Address In the event of a Failed Remarketing, Notes which are in book-entry form should be credited to the account at The Depository Trust Company to the person(s) set forth below. DTC Account Number: Name of Account Party: U.S. Bank National Association, as Custodial Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Notes Due 2042 of Xxxxxxx Controls, Inc. (the “Company”). The undersigned hereby notifies you in accordance with Section 5.03(d) of the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Agreement”), among the Company and you, as Collateral Agent, Custodial Agent and Securities Intermediary, and U.S. Bank National Association, as Purchase Contract Agent and as attorney-in-fact for the holders of Corporate Units and Treasury Units from time to time, that the undersigned elects to withdraw the $ aggregate principal amount of Separate Notes delivered to you for Remarketing pursuant to Section 5.03 of the Agreement. The undersigned hereby instructs you to return such Separate Notes to the undersigned in accordance with the undersigned’s instructions. With this notice, the Undersigned hereby agrees to be bound by the terms and conditions of Section 5.03(d) of the Agreement. Capitalized terms used herein but not defined shall have the meaning set forth in the Agreement. Date: By: Name: Title: Signature Guarantee: Name Address U.S. Bank National Association, as Purchase Contract Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”) The undersigned Holder hereby irrevocably notifies you in accordance with Section 5.03(b)(iii) of the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Purchase Contract and Pledge Agreement”; unless otherwise defined herein, terms defined in the Purchase Contract and Pledge Agreement are used herein as defined therein), among the Company and you, as Purchase Contract Agent, as attorney-in-fact for the Holders of the Corporate Units, Collateral Agent, Custodial Agent and Securities Intermediary, that such Holder has elected to pay to the Securities Intermediary for deposit in the Collateral Account, on or prior to 4:00 p.m. (New York City time) on the Business Day immediately preceding the Purchase Contract Settlement Date (in lawful money of the United States by certified or cashiers check or wire transfer, in immediately available funds payable to or upon the order of the Securities Intermediary), $ as the Purchase Price for the shares of Common Stock issuable to such Holder by the Company with respect to Purchase Contracts on the Purchase Contract Settlement Date. The undersigned Holder hereby instructs you to notify promptly the Collateral Agent of the undersigned Holders’ election to settle the Purchase Contracts related to such Holder’s Corporate Units with separate cash. Date: Signature: Signature Guarantee: Please print name and address of Registered Holder: NOTICE FROM PURCHASE CONTRACT AGENT TO COLLATERAL AGENT (Settlement with Separate Cash) U.S. Bank National Association, as Collateral Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”) Please refer to the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Agreement”), among the Company, you, as Collateral Agent, as Securities Intermediary and as Custodial Agent, and the undersigned, as Purchase Contract Agent and as attorney-in-fact for the Holders of Corporate Units from time to time. Capitalized terms used herein but not defined shall have the meaning set forth in the Agreement. We hereby notify you in accordance with Section 5.03(b)(iii) of the Agreement that the Holder of Corporate Units named below (the “Holder”) has elected to settle the Purchase Contracts related to its Pledged Applicable Ownership Interests in Notes with $ of separate cash prior to 11:00 a.m. (New York City time) on the second Business Day immediately preceding the Purchase Contract Settlement Date (in lawful money of the United States by certified or cashiers check or wire transfer, in immediately available funds payable to or upon the order of the Securities Intermediary) and has delivered to the undersigned a notice to that effect. We hereby request that you, upon confirmation that the Purchase Price has been paid by the Holder to the Securities Intermediary in accordance with Section 5.03(b)(iii) of the Agreement in lieu of exercise of such Holder’s Put Right, give us notice of the receipt of such payment and (A) promptly invest the separate cash received in Permitted Investments consistent with the instructions of the Company as provided in Section 5.03(a)(v) of the Agreement with respect to Cash Settlement, (B) promptly release from the Pledge the Notes underlying the Applicable Ownership Interest in Notes related to the Corporate Units as to which such Holder has paid such separate cash; and (C) promptly Transfer all such Notes to us for distribution to such Holder, in each case free and clear of the Pledge created by the Agreement. Date: ________________________, U.S. Bank National Association, as Purchase Contract Agent and as attorney-in-fact of the Holders from time to time of the Units By: Name: Title: Authorized Signatory Please print name and address of Holder electing to settle with separate cash: Name: Social Security or other Taxpayer Identification Number, if any Address: NOTICE OF SETTLEMENT WITH SEPARATE CASH FROM SECURITIES INTERMEDIARY TO PURCHASE CONTRACT AGENT (Settlement with Separate Cash) U.S. Bank National Association, as Purchase Contract Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc. (the “Company”) Please refer to the Purchase Contract and Pledge Agreement dated as of March 16, 2009 (the “Agreement”), by and among you, the Company, and U.S. Bank National Association, as Collateral Agent, Custodial Agent and Securities Intermediary. Unless otherwise defined herein, terms defined in the Agreement are used herein as defined therein. In accordance with Section 5.03(b)(iii) of the Agreement, we hereby notify you that as of 4:00 p.m. (New York City time) on the Business Day immediately preceding March 31, 2012 (the “Purchase Contract Settlement Date”), (i) we have received from $ in immediately available funds paid in an aggregate amount equal to the Purchase Price due to the Company on the Purchase Contract Settlement Date with respect to Corporate Units and (ii) based on the funds received set forth in clause (i) above, an aggregate principal amount of $ of Notes underlying related Pledged Applicable Ownership Interests in Notes are to be released from the Pledge and Transferred to you. U.S. Bank National Association, as Securities Intermediary Dated: By: [______________________] U.S. Bank National Association 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Ladies and Gentlemen: This Agreement is dated as of [•] (the “Agreement”) by and among Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”), [_______________________], as the reset agent and the remarketing agent (the “Remarketing Agent”), and U.S. Bank National Association, a national banking association, not individually but solely as Purchase Contract Agent (the “Purchase Contract Agent”) and as attorney-in-fact of the holders of Purchase Contracts (as defined in the Purchase Contract and Pledge Agreement referred to below).
Suspension or Debarment Instructions Instructions for Certification 1. By answering yes to the next Attribute question below, the vendor and prospective lower tier participant is providing the certification set out herein in accordance with these instructions.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Billing Instructions Enter name and mailing address of nominating Agency Finance Office for billing purposes.
