Subcontracting 6.1 The Grantee is responsible for the performance of its obligations under this Agreement, including in relation to any tasks undertaken by subcontractors.
6.2 The Grantee agrees to make available to the Commonwealth the details of any of its subcontractors engaged to perform any tasks in relation to this Agreement upon request.
Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity
1.1.02 Identify at least one individual to act as the program contact in the following areas:
1. Immunization Program Manager;
Quality Management Grantee will:
1. comply with quality management requirements as directed by the System Agency.
2. develop and implement a Quality Management Plan (QMP) that conforms with 25 TAC § 448.504 and make the QMP available to System Agency upon request. The QMP must be developed no later than the end of the first quarter of the Contract term.
3. update and revise the QMP each biennium or sooner, if necessary. Xxxxxxx’s governing body will review and approve the initial QMP, within the first quarter of the Contract term, and each updated and revised QMP thereafter. The QMP must describe Xxxxxxx’s methods to measure, assess, and improve -
i. Implementation of evidence-based practices, programs and research-based approaches to service delivery;
ii. Client/participant satisfaction with the services provided by Xxxxxxx;
iii. Service capacity and access to services;
iv. Client/participant continuum of care; and
v. Accuracy of data reported to the state.
4. participate in continuous quality improvement (CQI) activities as defined and scheduled by the state including, but not limited to data verification, performing self-reviews; submitting self-review results and supporting documentation for the state’s desk reviews; and participating in the state’s onsite or desk reviews.
5. submit plan of improvement or corrective action plan and supporting documentation as requested by System Agency.
6. participate in and actively pursue CQI activities that support performance and outcomes improvement.
7. respond to consultation recommendations by System Agency, which may include, but are not limited to the following:
i. Staff training;
ii. Self-monitoring activities guided by System Agency, including use of quality management tools to self-identify compliance issues; and
iii. Monitoring of performance reports in the System Agency electronic clinical management system.
Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout
Contract Management To ensure full performance of the Contract and compliance with applicable law, the System Agency may take actions including:
a. Suspending all or part of the Contract;
b. Requiring the Grantee to take specific corrective actions in order to remain in compliance with term of the Contract;
c. Recouping payments made to the Grantee found to be in error;
d. Suspending, limiting, or placing conditions on the continued performance of the Project;
e. Imposing any other remedies authorized under this Contract; and
f. Imposing any other remedies, sanctions or penalties permitted by federal or state statute, law, regulation, or rule.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Subcontract An agreement by the contractor to employ a subcontractor to provide services to fulfill this contract.
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Subcontracts The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (1.) through (4.) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1.) through (4.) of this section.
Workload Management 11.1 The parties to this Agreement acknowledge that employees and management have a responsibility to maintain a balanced workload and recognise the adverse affects that excessive workloads may have on employee/s and the quality of resident/client care.
11.2 To ensure that employee concerns involving excessive workloads are effectively dealt with by Management the following procedures should be applied:
(a) Step 1: In the first instance, employee/s should discuss the issue with their immediate supervisor and, where appropriate, explore solutions.
(b) Step 2: If a solution cannot be identified and implemented, the matter should be referred to an appropriate senior manager for further discussion.
(c) Step 3: If a solution still cannot be identified and implemented, the matter should be referred to the Facility Manager for further discussion.
(d) Step 4: The outcome of the discussions at each level and any proposed solutions should be recorded in writing and fed back to the effected employees.
11.3 Workload management must be an agenda item at staff meetings on at least a quarterly basis. Items in relation to workloads must be recorded in the minutes of the staff meeting, as well as actions to be taken to resolve the workloads issue/s. Resolution of workload issues should be based on the following criteria including but not limited to:
(a) Clinical assessment of residents’ needs;
(b) The demand of the environment such as facility layout;
(c) Statutory obligation, (including, but not limited to, work health and safety legislation);
(d) The requirements of nurse regulatory legislation;
(e) Reasonable workloads (such as roster arrangements);
(f) Accreditation standards; and
(g) Budgetary considerations.
11.4 If the issue is still unresolved, the employee/s may advance the matter through Clause 9 Dispute Resolution Procedure. Arbitration of workload management issues may only occur by agreement of the employer and the employee representative, which may include the union/s.
