Landlord’s Approval Tenant shall not make, or allow to be made, any alterations, physical additions, improvements or partitions, including without limitation the attachment of any fixtures or equipment, in, about or to the Premises (“Alterations”) without obtaining the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed with respect to proposed Alterations which: (i) comply with all Applicable Laws; (ii) are, in Landlord’s opinion, compatible with the Building or the Project and the Base Building Systems , and will not cause the Building or Project or Base Building Systems to be required to be modified to comply with any Applicable Laws (including, without limitation, the Americans With Disabilities Act); and (iii) will not unreasonably interfere with or materially disturb the use and occupancy of any other portion of the Building or Project by any other tenant or its invitees. Specifically, but without limiting the generality of the foregoing, Landlord shall have the right to approve all plans and specifications for the proposed Alterations, construction means and methods, all appropriate permits and licenses, any contractor or subcontractor to be employed on the work of Alterations, and the time for performance of such work, and may impose reasonable rules and regulations for contractors and subcontractors performing such work. Landlord may, in its sole discretion, specify engineers, general contractors, subcontractors, and architects to perform work affecting the Base Building Systems. Tenant shall also supply to Landlord any documents and information reasonably requested by Landlord in connection with Landlord’s consideration of a request for approval hereunder. No review or consent by Landlord of or to any proposed Alteration or additional work shall constitute a waiver of Tenant’s obligations under this Paragraph 12, nor constitute any warranty or representation that the same complies with all Applicable Laws, for which Tenant shall at all times be solely responsible. Tenant shall reimburse Landlord for all out-of-pocket, reasonable costs which Landlord may incur in connection with granting approval to Tenant for any such Alterations, including any costs or expenses which Landlord may incur in electing to have outside architects and engineers review said plans and specifications. Tenant shall also pay to Landlord a fee for its review of plans and its management and supervision of the progress of the work in an amount equal to three percent (3%) of the cost of any Alterations (other than for Minor Alterations). The Tenant Improvements constructed pursuant to the Tenant Improvement Agreement shall not be deemed to be Alterations hereunder.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.
Landlord Approval (Check one)
Tenant’s Alterations (a) Except as hereafter provided, Tenant shall make no alterations, additions or improvements (“Tenant Alterations”) to the Leased Space without the consent of Landlord, which consent shall not be unreasonably withheld, delayed or conditioned. At the time of Landlord’s consent, Landlord shall designate whether Tenant shall be required to remove the proposed Tenant Alteration upon termination of this Lease, and the absence of such designation in Landlord’s written consent shall be deemed Landlord’s agreement that Tenant shall not be obligated to remove Tenant Alterations upon the termination of this Lease. Landlord also may impose such reasonable conditions as part of its consent as Landlord deems appropriate, taking into consideration the nature of the proposed Tenant Alteration, including, without limitation, requiring Tenant to furnish Landlord with security for the payment of all costs to be incurred in connection with such work, insurance, and copies of the plans, specifications and permits necessary for such work. Nothing herein, however, shall be construed to obligate Tenant to construct any Tenant Alteration for which Landlord has given its consent.
(b) Landlord’s consent shall not be required for Tenant Alterations which (i) do not adversely impact the structural integrity of the Building or the systems serving the Building or their operation, (ii) are not visible from the Building exterior and (iii) qualify under the following:
(A) The Tenant Alteration is to be made to portions of the Leased Premises other than the laboratory areas and the cost thereof is $10,000 or less with respect to any Tenant Alteration project (or $20,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period); or
(B) The Tenant Alteration is to be made to the laboratory areas of the Leased Premises and the cost thereof is $50,000 or less with respect to any Tenant Alteration project (or $100,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period). Tenant Alterations described in this subsection (b) for which Landlord’s consent is not required hereinafter are called “Permitted Tenant Alterations.” Notwithstanding the foregoing, painting or carpeting of the interior of the Leased Space and like cosmetic improvements shall not be deemed Tenant Alterations regardless of the cost thereof. Tenant shall not be obligated to remove Permitted Tenant Alterations upon the termination of this Lease unless an Event of Default has occurred which is then continuing and Landlord so requires such removal.
(c) All Tenant Alterations shall be done at Tenant’s expense by contractors approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed given unless Landlord notifies Tenant of its objections within ten (10) business days after delivery of Tenant’s request for approval. With respect to Tenant Alterations other than the Permitted Tenant Alterations, no work shall be performed until the plans therefore have been approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed approved unless Landlord notifies Tenant of objections to the proposed plans within ten (10) business days after delivery to Landlord of a complete set of the plans therefor. In connection with the review of plans submitted by Tenant, Landlord shall be reimbursed by Tenant for Landlord’s cost in reviewing such plans at the rate of $125.00 per hour; subject to reasonable increase to reflect the then current hourly charge imposed for such review by Landlord for its tenants in the Center generally, and prior to undertaking any such review, Landlord shall provide a statement of the maximum review hours to be dedicated to such review. With respect to Permitted Tenant Alterations, Tenant shall provide Landlord with a copy of Tenant’s application for a building permit therefor, if applicable (together with all attachments thereto), and no review fee shall be charged to Tenant by Landlord in connection therewith nor shall Landlord’s approval of such application be required. Tenant shall provide copies of as-built plans and specifications for all Tenant Alterations to Landlord within a reasonable time of completion of the Tenant Alteration. All Tenant Alterations shall be done in a first class, workmanlike manner and shall comply with all insurance requirements then made available to Tenant and all applicable laws, ordinances, rules and regulations of governmental authorities having jurisdiction thereover, and, where applicable, with all reasonable requirements of Landlord imposed as a condition of such consent.
(d) If, as a condition of Landlord’s consent, removal of a Tenant Alteration is required at termination of this Lease, Tenant shall promptly remove such Tenant Alterations and repair any damage occasioned by such removal. In default thereof, Landlord may effect said removal and repairs at Tenants expense. With respect to any Tenant Alterations which Tenant is not obligated to remove hereunder (including without limitation Permitted Tenant Alterations), such Tenant Alterations, if not removed by Tenant upon the termination of this Lease, shall be deemed abandoned by Tenant, and deemed a part of Landlord’s property, notwithstanding any provision of Section 16 to the contrary.
Alterations to Premises Tenant shall make no structural or interior alterations to the Premises. If Tenant requests such alterations and such alterations are structural in nature, then Tenant shall provide Landlord with a complete set of construction drawings. If Landlord consents to the alterations, then the Landlord shall determine the actual cost of the work to be done. Tenant may then either agree to pay Landlord to have the work done or withdraw its request for alterations; provided, however, that at Tenant’s request, Landlord shall not unreasonably withhold its consent to allowing Tenant and/or Tenant’s contractors to perform such work. All such alterations are subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to the terms of this paragraph, and notwithstanding any provision of this Lease to the contrary, Landlord agrees to allow Tenant to construct (i) a data center within the Premises and to install equipment (which may include generator, condensers, UPS, etc.) in the Building and around the land surrounding the Building necessary to facilitate the operation of Tenant’s data center, and (ii) an opening in the curtain wall of Floor 1 of Building C, to install two (2) four foot doors within such opening, to improve the outside area for delivery access and to install other improvements (which may include a large dumpster) to the Building and the land surrounding the Building necessary to facilitate the operation of Tenant’s Fulfillment Center. All such alterations shall be performed by Tenant’s contractors (which shall be subject to Landlord’s approval, not to be unreasonably withheld), at Tenant’s sole cost and expense. Notwithstanding the above paragraph, Tenant shall have the right to make nonstructural and nonsystems related alterations (“Tenant Alterations”) up to a value of $15,000.00 per occurrence (not to exceed $60,000 during any 12-month period) without Landlord’s prior written consent (which consent shall not be unreasonably withheld), provided Tenant shall provide notice to Landlord of its intent to make the Tenant Alterations. Such notice shall include a copy of plans and specifications (if such alterations are of a character that would reasonably require plans and specifications) and copies of all permits, if required by the appropriate municipality, and any contracts for such Tenant Alterations. All Tenant Alterations shall be performed by contractors approved by Landlord which approval shall not be unreasonably withheld, and in accordance with all applicable laws and the rules and regulations described in Section 12b.
Landlord’s Consent Landlord shall not unreasonably withhold or delay its consent to any proposed Transfer of the Subject Space to the Transferee on the terms specified in the Transfer Notice. Without limitation as to other reasonable grounds for withholding consent, the parties hereby agree that it shall be reasonable under this Lease and under any applicable law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply:
14.2.1 The Transferee is of a character or reputation or engaged in a business which is not consistent with the quality of the Building or the Project;
14.2.2 The Transferee is either a governmental agency or instrumentality thereof;
14.2.3 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the responsibilities to be undertaken in connection with the Transfer on the date consent is requested; or
14.2.4 The proposed Transfer would cause a violation of another lease for space in the Project, or would give an occupant of the Project a right to cancel its lease. If Landlord consents to any Transfer pursuant to the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 of this Lease), Tenant may within six (6) months after Landlord’s consent, but not later than the expiration of said six-month period, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 of this Lease, provided that if there are any changes in the terms and conditions from those specified in the Transfer Notice such that Landlord would initially have been entitled to refuse its consent to such Transfer under this Section 14.2, Tenant shall again submit the Transfer to Landlord for its approval and other action under this Article 14 (including Landlord’s right of recapture, if any, under Section 14.4 of this Lease). Notwithstanding anything to the contrary in this Lease, if Tenant or any proposed Transferee claims that Landlord has unreasonably withheld or delayed its consent under Section 14.2 or otherwise has breached or acted unreasonably under this Article 14, their sole remedies shall be a suit for contract damages (other than damages for injury to, or interference with, Tenant’s business including, without limitation, loss of profits, however occurring) or declaratory judgment and an injunction for the relief sought, and Tenant hereby waives all other remedies, including, without limitation, any right at law or equity to terminate this Lease, on its own behalf and, to the extent permitted under all applicable laws, on behalf of the proposed Transferee.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above.
(b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01.
(c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,.
(d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions:
1. Actual cost of the Landlord Improvements: $100,000.00
2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75
(e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements:
(i) Replace all stained, damaged or missing ceiling tiles,
(ii) Paint all walls in the Leased Premises, the color to be designated by Tenant,
(iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C,
(iv) Shampoo all carpets in the office areas and hallways and
(v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use.
(vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface
(vii) Repair any existing alligator or pothole areas.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
