Sufficient Funds Buyer has, and will have at the Effective Time, sufficient funds to consummate the transactions contemplated by this Agreement, subject to the terms and conditions of this Agreement.
Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Sale : Completion On Or Before The Completion Date
a. Within ninety (90) days from the date of successful sale (the expiry date of which period referred to as “the Completion Date”), the Purchaser shall deposit with the Assignee’s Solicitors simultaneously:-
(i) The balance of the purchase price i.e a sum equivalent to 90% of the successful bid price (referred to as “the Balance Sum”) either by way of IBG or XXXXXX or bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to HONG XXXXX BANK BERHAD. The amount of the bank draft or cashier’s order shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and
(ii) A copy of the requisite consents or confirmations (as the case may be) of the Developer and/or Proprietor and/or State Authorities and/or relevant bodies approving the sale (including transfer or assignment) in favour of the Purchaser, if necessary and/or required, subject firstly to the Assignee being satisfied with the conditions if imposed, otherwise the Assignee may elect to terminate the sale under Xxxxxx 11. - Extension
b. The Completion Date will not be extended unless the Purchaser shall have at least fourteen (14) days before the Completion Date applied in writing for an extension of time to the Assignee and the Assignee may at its absolute discretion without assigning any reason whatsoever either:-
(i) Reject such request in which event all monies paid by the Purchaser hitherto including the Deposit shall be forfeited absolutely and immediately for which the Purchaser shall not be entitled to nor have any or further reimbursements, claims and demands whatsoever in nature and howsoever caused against the Assignee, the Assignee’s Solicitors, the Auctioneer or their respective servants or agents and any other party on account thereof; or
(ii) Agree to grant an extension of time subject to conditions imposed by the Assignee including but not limited to the imposition of non- refundable late payment charges / compensation charges on the balance unpaid or outstanding purchase price at such rate as the Assignee shall determine and to be calculated on a daily basis for the whole duration of the extended period granted and also to pay such sum within the time and in the manner as stipulated by the Assignee. Such decision by the Assignee shall be binding on the Purchaser. - Charges
c. Notwithstanding any contrary terms and conditions which may be imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto on the Assignee in granting the consent or confirmation (as the case may be) to the sale herein, it is hereby agreed that only arrears of quit rent, assessment rate and service charges (collectively referred to as “the Outstanding Charges”) within a period of six (6) years prior to the date of successful sale of the Property which are lawfully and rightfully due and payable to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto up to the date of successful sale of the Property shall be deducted from the purchase price upon receipt of the Balance Sum PROVIDED THAT the Assignee reserves the right to refuse to pay nor shall the Assignee be obliged to pay:-
(i) Any Outstanding Charges that are time-barred i.e. charges which have remained unpaid for more than six (6) years prior to the date of successful sale of the Property irrespective of any payment or acknowledgement or judgment made or obtained on the said charges;
(ii) Any Outstanding Charges that are excessively charged resulted from eg duplicate or double counting, wrong calculation or any other similar circumstances;
(iii) Any Outstanding Charges wrongfully imposed including but not limited to being charged without any basis whatsoever; and/or
(iv) Any bills issued by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto for the Outstanding Charges but only received by the Assignee or the Assignee’s Solicitors more than seventy-five (75) days from the date of the successful sale. Such decision by Assignee on what is due and payable shall be binding on the Purchaser of which the Purchaser hereby expressly agrees.
d. The Outstanding Charges due and payable immediately after the date of successful sale of the Property shall be solely borne and paid by the Purchaser.
e. Where applicable, it shall be the duty of the Purchaser to obtain at the Purchaser’s own costs the particulars as stated in Section 22D(4) of the Housing Development (Control and Licensing) Act 1966 and to obtain copies of the charges payable from the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto and to forward copies thereof together with the calculations as to the apportionment of the respective parties’ liability thereof to the Assignee’s Solicitors for the Assignee’s approval. For this purpose, the Purchaser shall also furnish the Assignee’s Solicitors with the Purchaser’s account details in order for the Assignee to process payment of the Assignee’s portion of the Outstanding Charges pursuant to and in accordance with Clause 8(c) above.
f. In the event the Purchaser shall pay such arrears (if any) of the Outstanding Charges in advance to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto:-
(i) The Purchaser is not entitled to deduct the payment towards the arrears (if any) from the Balance Sum;
(ii) Due apportionment and reimbursement for the payment (if any) made by the Purchaser towards the arrears shall only be made after the Assignee has received the Balance Sum and subject to the Assignee’s approval and other provisions of these Conditions of Sale. For this purpose, the Purchaser shall produce receipts evidencing payment together with the Purchaser’s account details in order for the Assignee to reimburse the Purchaser in accordance with this Clause 8(f)(ii) accordingly.
g. Nothing herein shall impose any obligation on the part of the Assignee to pay any outstanding water, electricity, telephone, utilities, gas, sewerage, taxes, rates, bills, any type of interest, fine, penalty, losses incurred by reason of any breach of written laws, late payment charges, damages, compensation, other form of maintenance or management charges (including but not limited to security charges, charges incurred in relation to car park / accessory parcel, deposits, sinking / building / common / maintenance / management fund), costs for renovation / alteration / additional works, contribution, subscription, licence, dues, levies, insurance, premium, rents, commission, fees, costs and expenses (including but not limited to legal fees, disbursements, stamp duty, registration fees, administrative or vetting fees and transfer costs), other outgoings and charges in any form whatsoever (including for any increase in area of the Property imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto irrespective of whether the same was imposed or incurred before the date of successful auction, any penalty thereof in connection with incidental to or pursuant to the Assignment the Memorandum of Transfer and all other documents necessary for affecting the transfer or subsequent transfer [as the case may be] or assigning the beneficial ownership of the Property to the Purchaser or that as may be due to or imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto notwithstanding that the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto may require such payments to be made by the Assignee). The Purchaser hereby expressly agrees that such costs and expenses shall be solely borne and paid by the Purchaser.
h. Any other costs, expenses and charges not specifically mentioned and/or specified in Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f and Clause 8.g hereof which are outstanding shall be solely borne and paid by the Purchaser.
i. Upon payment of all monies mentioned and/or specified in Clause 6.d, Clause 7.a, Clause 8.a(i), Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f, Clause 8.g and Clause 8.h above and subject to the fulfillment of Clause 9 below by the Purchaser, the Assignee shall:-
(i) Execute or cause to be executed as soon as possible at the Purchaser’s own costs and expenses (including legal fees, stamp duty and registration fees) an Assignment (in the form and substance acceptable to and upon the terms and conditions stipulated by the Assignee at its absolute discretion) in favour of the Purchaser of all the rights title interests and benefits under the Sale and Purchase Agreement entered into between the Developer and/or Proprietor of the Property and the Assignor or the original purchaser(s) when the Assignor is not the original purchaser of the Property. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the Assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the Property. The Assignee shall not be required to assign the Property to any person other than the Purchaser; and
(ii) Deliver to the Purchaser or the Purchaser’s Solicitors the duly executed Assignment and certified true copy(ies) of the Sale and Purchase Agreement and previous Assignment within the Assignee’s custody. If any of the aforesaid documents is not available, the Assignee shall use its best endeavors to provide certified true copy(ies) or such other acceptable documentary evidence of previous transactions thereof.
j. Where applicable, the Purchaser undertakes to forward to the Developer the duly stamped Assignment, the duly stamped Proclamation of Sale and the Memorandum together with the full payment of all sums and outgoings due to the Developer under the Sale and Purchase Agreement as required by Section 22D(2) of the Housing Development (Control and Licensing) Act 1966 within fourteen (14) days from the date of stamping of the Assignment and to forward a copy of the cover letter or acknowledgment of receipt by the Developer to the Assignee or the Assignee’s Solicitors within seven (7) days after the issuance of the cover letter or acknowledgment of receipt. - Charge / Transfer
k. If the separate document of title or strata title for the Property has been issued whether before on or after the date of auction sale, the Assignee shall not be required to procure a Memorandum of Transfer nor to register its charge as prescribed by the National Land Code 1965 or Sarawak Land Code or the Land Ordinance Cap. 68 of the Laws of Sabah (where applicable) in favour of the Purchaser from the Developer and/or Proprietor (as the case may be).
l. The transfer of the Property from the Developer and/or Proprietor (as the case may be) shall be prepared and procured by the Purchaser at the Purchaser’s own costs (including costs of transfer from the Developer and/or Proprietor to the Assignor where necessary) and expenses who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies pertaining to the registration of such transfer of the Property.
m. The Purchaser undertakes to inform the local authority of the change of ownership and to file the necessary form within fourteen (14) days from the date of stamping of the Assignment.
TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
Deliveries at Closing Buyers’ Parent shall have delivered or caused to be delivered to Sellers’ Representative the following documents, each properly executed and dated as of the Closing Date, and in form and substance reasonably acceptable to Sellers’ Representative:
(a) the Tredegar Brasil Deliverables set forth in Section 2 of Exhibit D;
(b) the Tredegar India Interests Purchase Agreement and the documents and instruments set forth in Section 2.4 thereunder that are required to be delivered at Closing in order to effect the purchase and sale of the Tredegar India Interests and the transfer of legal ownership of the Nominee Interest as contemplated thereby;
(c) a certificate of an authorized officer of Buyers’ Parent certifying as to the satisfaction of the closing conditions set forth in Sections 9.1 and 9.2;
(d) a certificate of the secretary or other authorized officer of Buyers’ Parent certifying as to: (i) the accuracy and completeness of attached copies of the Organizational Documents of each Buyer certified by the applicable Governmental Authority as of a recent date, and (ii) the resolutions of the equityholders of Buyers, if required, and the board of directors or the board of managers, as applicable, of Buyers authorizing and approving the execution and delivery of this Agreement by Buyer and all other agreements contemplated hereby, the performance of Buyers’ obligations hereunder and thereunder and the consummation of the transactions contemplated hereby and thereby;
(e) instruments necessary to effect the replacement, effective as of Closing, of the directors, managers and officers, as applicable, of the Target Companies and Target Subsidiaries set forth on Annex 8.5(h), including, as required by applicable Law, resolutions of the governing bodies of a Target Company or any Target Subsidiary and amendments to applicable Organizational Documents;
(f) the Escrow Agreement; and
(g) the Transition Services Agreement.
Post-Closing Access (a) Each of Seller and Buyer shall, and Buyer shall cause the Company to, preserve and keep all books and records and other information relating to the accounting, legal, Tax, regulatory, business and financial affairs of the Company and the Rolling Mill Business for a period of seven (7) years after the Closing Date (or, in the case of information relating to Taxes, until the expiration of any applicable statute of limitations), or for a longer period if (i) required by Law (including any statute of limitations and applicable extensions thereof) or any Governmental Authority or (ii) reasonably necessary with respect to the prosecution or defense of any audit or other legal or regulatory action that is then pending or threatened so long as the requesting Party has notified the other Party with prior written notice of the need to retain such books, records or information.
(b) Following the Closing, for so long as such information is retained by Buyer in accordance with Section 5.8(a), Buyer shall, and shall cause the Company, to permit Seller and its authorized Representatives, at Seller’s sole cost and expense, to have reasonable access and duplication rights during normal business hours, upon reasonable prior written notice to Buyer to the information described in Section 5.8(a) to the extent that such access may be reasonably required in connection with (i) the preparation of any Tax Return, accounting records or with respect to any Tax Claim or similar proceedings, (ii) any Action relating to Seller, the Company or the Rolling Mill Business, (iii) any Governmental Filing or matter (including investigations by Governmental Authorities) or (iv) any other valid legal or business purpose. Notwithstanding the foregoing, Seller shall have no right of access to, and Buyer shall have no obligation to provide, (A) any information if doing so would reasonably be expected to (1) violate any Contract or Law to which Buyer or any of its Affiliates (including the Company) is a party or is subject, (2) result in a loss of the ability to successfully assert a claim of privilege (including the attorney-client and work product privileges), (3) result in the disclosure of any competitively sensitive information of Buyer or of any of its Affiliates (including the Company), or (4) breach a confidentiality or other obligation to a Third Party (provided that Buyer shall use commercially reasonable efforts to obtain the consent of any Third Party with regards to such disclosure), or (B) any consolidated, combined, affiliated or unitary Tax Return which includes Buyer or any of its Affiliates (including the Company) or any Tax-related work papers.
(c) Following the Closing, for so long as such information is retained by Seller in accordance with Section 5.8(a), Seller shall permit Buyer and its authorized Representatives, at Buyer’s sole cost and expense, to have reasonable access and duplication rights during normal business hours, upon reasonable prior written notice to Seller, to the information described in Section 5.8(a) to the extent that such access may be reasonably required in connection with (i) the preparation of any Tax Return, accounting records or with any Tax Claim or similar proceedings, (ii) any Action relating to the Company or the Rolling Mill Business, (iii) any Governmental Filing or matter (including investigations by Governmental Authorities) or (iv) any other valid legal or business purpose. Notwithstanding the foregoing, Buyer shall have no right of access to, and Seller shall have no obligation to provide, (A) any information if doing so would reasonably be expected to (1) violate any Contract or Law to which Seller or any of its Affiliates is a party or is subject,
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.
Deliveries at the Closing At the Closing: -------------------------
(a) Seller and/or Parent shall deliver or cause to be delivered to Buyer the following:
(i) a good and sufficient xxxx of sale for the Assets, selling, delivering, transferring and assigning to Buyer all of Seller's and Affiliate's right, title and interest in and to the Assets, free and clear of any and all Liens other than Permitted Liens, in substantially the form attached hereto as Exhibit A (the "Xxxx of Sale"), together with such assignments and --------- ------------ other documentation reasonably requested by, and in form and substance reasonably satisfactory to, Buyer to validly vest Buyer with all of Seller's and Affiliate's right, title and interest in or to the Assets, free and clear of all Liens other than Permitted Liens;
(ii) consents, in substantially the form attached hereto as Exhibit B-1, to the assignment of the contracts listed on Schedules 2.30 and ----------- -------------- 2.31 of the Seller Disclosure Schedule; ----
(iii) copies, certified by an authorized officer of Seller, of minutes or resolutions of the board of directors and Parent, as sole stockholder, which shall not have been rescinded or modified, unconditionally authorizing the execution of this Agreement and the performance of the transactions contemplated hereby;
(iv) copies, certified by an authorized officer of Parent, of minutes or resolutions of the board of directors, which shall not have been rescinded or modified, unconditionally authorizing the execution of this Agreement and the performance of the transactions contemplated hereby;
(v) the Escrow Agreement, in substantially the form attached hereto as Exhibit D (the "Escrow Agreement"), executed by each of --------- ---------------- Seller and Parent;
(vi) documents in form and substance reasonably satisfactory to Buyer and its counsel evidencing that the approvals and consents specified in Sections 6.1(c) and 6.3(c) hereof have been obtained and are in full force and effect; and
(vii) all other documents and instruments required hereunder to be delivered by Seller to Buyer at the Closing;
(b) Buyer shall deliver or cause to be delivered to Seller the following:
(i) an instrument of assumption of liabilities, in substantially the form attached hereto as Exhibit C, by which Buyer shall assume --------- the Assumed Liabilities as of the Closing, together with such other documentation reasonably requested by Seller to cause Buyer to assume the Assumed Liabilities;
(ii) the Escrow Agreement executed by Buyer; and
(iii) all other documents and instruments required hereunder to be delivered by Buyer to Seller at the Closing;
(c) Buyer shall deposit the Escrow Amount with the Escrow Agent in accordance with Article VIII and the Escrow Agreement. ------------
