Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.
Trustee Not Required to Make Investigation Prior to the occurrence of an Event of Default hereunder and after the curing of all Events of Default which may have occurred, the Trustee shall not be bound to make any investigation into the facts or matters stated in any resolution, certificate, statement, instrument, opinion, report, notice, request, consent, order, appraisal, bond, Mortgage, Mortgage Note or other paper or document (provided the same appears regular on its face), unless requested in writing to do so by holders of Certificates evidencing in the aggregate not less than 51% of the Voting Interest represented by all Certificates; provided, however, that if the payment within a reasonable time to the Trustee of the costs, expenses or liabilities likely to be incurred by it in the making of such investigation is, in the opinion of the Trustee, not reasonably assured to the Trustee by the security afforded to it by the terms of this Agreement, the Trustee may require reasonable indemnity against such expense or liability as a condition to so proceeding. The reasonable expense of every such investigation shall be paid by the Master Servicer or, if paid by the Trustee shall be repaid by the Master Servicer upon demand.
Trustee’s Good Faith Action, Expert Advice, No Bond or Surety The exercise by the Trustees of their powers hereunder shall be binding upon everyone interested in or dealing with the Trust. A Trustee shall be liable to the Trust and to any Shareholder solely for his or her own willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of the office of Trustee, and shall not be liable for errors of judgment or mistakes of fact or law. The Trustees may take advice of counsel or other experts with respect to the meaning and operation of this Declaration of Trust, and shall be under no liability for any act or omission in accordance with such advice nor for failing to follow such advice. The Trustees shall not be required to give any bond as such, nor any surety if a bond is required.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of:
i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco;
ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area;
iii. Applying to all employees and visitors in this designated area; and
iv. Providing for or referring its employees to tobacco use cessation services.
B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Term of Agreement; Resignation and Removal of the Administrator (a) This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate.
(b) Subject to Section 8(e), the Administrator may resign its duties hereunder by providing the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice.
(c) Subject to Section 8(e), the Issuing Entity may remove the Administrator without cause by providing the Administrator, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice.
(d) Subject to Section 8(e), at the sole option of the Issuing Entity, the Administrator may be removed immediately upon written notice of termination from the Issuing Entity to the Administrator, the Trustee, the Indenture Trustee and the Servicer if any of the following events shall occur:
(i) the Administrator shall default in the performance of any of its duties under this Agreement and, after notice of such default, shall not cure such default within ten days (or, if such default cannot be cured in such time, shall not give within ten days such assurance of cure as shall be reasonably satisfactory to the Issuing Entity);
(ii) a court having jurisdiction in the premises shall enter a decree or order for relief, and such decree or order shall not have been vacated within 60 days, in respect of the Administrator in any involuntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect or appoint a receiver, liquidator, assignee, custodian, trustee, sequestrator or similar official for the Administrator or any substantial part of its property or order the winding-up or liquidation of its affairs; or
(iii) the Administrator shall commence a voluntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect, shall consent to the entry of an order for relief in an involuntary case under any such law, or shall consent to the appointment of a receiver, liquidator, assignee, trustee, custodian, sequestrator or similar official for the Administrator or any substantial part of its property, shall consent to the taking of possession by any such official of any substantial part of its property, shall make any general assignment for the benefit of creditors or shall fail generally to pay its debts as they become due. The Administrator agrees that if any of the events specified in clauses (ii) or (iii) of this subsection shall occur, it shall give written notice thereof to the Issuing Entity, the Servicer, the Trustee and the Indenture Trustee within seven days after the happening of such event.
(e) Upon the Administrator’s receipt of notice of termination, pursuant to Sections 8(c) or (d), or the Administrator’s resignation in accordance with this Agreement, the predecessor Administrator shall continue to perform its functions as Administrator under this Agreement, in the case of termination, only until the date specified in such termination notice or, if no such date is specified in a notice of termination, until receipt of such notice and, in the case of resignation, until the later of: (x) the date 45 days from the delivery to the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer of written notice of such resignation (or written confirmation of such notice) in accordance with this Agreement and (y) the date upon which the predecessor Administrator shall become unable to act as Administrator, as specified in the notice of resignation and accompanying Opinion of Counsel. In the event of the Administrator’s termination hereunder, the Issuing Entity shall appoint a successor Administrator acceptable to the Indenture Trustee, and the successor Administrator shall accept its appointment by a written assumption in form acceptable to the Indenture Trustee. In the event that a successor Administrator has not been appointed at the time when the predecessor Administrator has ceased to act as Administrator in accordance with this Section, and if the predecessor Administrator is currently serving as the Servicer under the Transaction Documents, the Indenture Trustee without further action shall automatically be appointed the successor Administrator and the Indenture Trustee shall be entitled to the compensation specified in Section 3. Notwithstanding the above, the Indenture Trustee shall, if it shall be unable so to act, appoint or petition a court of competent jurisdiction to appoint any established institution having a net worth of not less than $50,000,000 and whose regular business shall include the performance of functions similar to those of the Administrator, as the successor to the Administrator under this Agreement.
(f) Upon appointment, the successor Administrator (including the Indenture Trustee acting as successor Administrator) shall be the successor in all respects to the predecessor Administrator and shall be subject to all the responsibilities, duties and liabilities arising thereafter relating thereto placed on the predecessor Administrator and shall be entitled to the compensation specified in Section 3 and all the rights granted to the predecessor Administrator by the terms and provisions of this Agreement.
(g) Except when and if the Indenture Trustee is appointed successor Administrator, the Administrator may not resign unless it is prohibited from serving as such by law as evidenced by an Opinion of Counsel to such effect delivered to the Indenture Trustee. No resignation or removal of the Administrator pursuant to this Section shall be effective until: (i) a successor Administrator shall have been appointed by the Issuing Entity and (ii) such successor Administrator shall have agreed in writing to be bound by the terms of this Agreement in the same manner as the Administrator is bound hereunder.
(h) The appointment of any successor Administrator shall be effective only after satisfaction of the Rating Agency Condition with respect to the proposed appointment.
Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, inspection or investigation of the Grant Agreement and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency.
B. As part of the services, Grantee must provide to HHS upon request a copy of those portions of Grantee's and its Subcontractors' internal audit reports relating to the services and Deliverables provided to the State under the Grant Agreement.
C. Grantee shall include the requirement to provide to System Agency (and any of its duly authorized federal, state, or local authorities) internal audit reports related to this Grant Agreement in any Subcontract it awards. Upon request by System Agency, Grantee shall enforce this requirement against its Subcontractor. Further, Grantee shall include in any Subcontract it awards a requirement that all Subcontractor Subcontracts must also include these provisions.
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
No Responsibility for Advances, Creditworthiness, Collateral, Recitals, Etc [Intentionally Omitted. See Sections 7.03 and 7.04 of the Credit Agreement for these provisions.]
