Supplemental HVAC If any supplemental HVAC unit (a “Unit”) serves the Premises, then (a) Tenant shall pay the costs of all electricity consumed in the Unit’s operation, together with the cost of installing a meter to measure such consumption; (b) Tenant, at its expense, shall (i) operate and maintain the Unit in compliance with all applicable Laws and such reasonable rules and procedures as Landlord may impose; (ii) keep the Unit in as good working order and condition as exists upon its installation (or, if later, on the date Tenant takes possession of the Premises), subject to normal wear and tear and damage resulting from Casualty; (iii) maintain in effect, with a contractor reasonably approved by Landlord, a contract for the maintenance and repair of the Unit, which contract shall require the contractor, at least once every three (3) months, to inspect the Unit and provide to Tenant a report of any defective conditions, together with any recommendations for maintenance, repair or parts-replacement; (iv) follow all reasonable recommendation of such contractor; and (v) promptly provide to Landlord a copy of such contract and each report issued thereunder; (c) the Unit shall become Landlord’s property upon installation and without compensation to Tenant; provided, however, that upon Landlord’s request at the expiration or earlier termination hereof, Tenant, at its expense, shall remove the Unit and repair any resulting damage; (d) the Unit shall be deemed (i) a Leasehold Improvement (except for purposes of Section 8), and (ii) for purposes of Section 11, part of the Premises; (e) if the Unit exists on the date of mutual execution and delivery hereof, Tenant accepts the Unit in its “as is” condition, without representation or warranty as to quality, condition, fitness for use or any other matter; (f) if the Unit connects to the Building’s condenser water loop (if any), then Tenant shall pay to Landlord, as Additional Rent, Landlord’s standard one-time fee for such connection and Landlord’s standard monthly per-ton usage fee; and (g) if any portion of the Unit is located on the roof, then (i) Tenant’s access to the roof shall be subject to such reasonable rules and procedures as Landlord may impose; (ii) Tenant shall maintain the affected portion of the roof in a clean and orderly condition and shall not interfere with use of the roof by Landlord or any other tenants or licensees; and (iii) Landlord may relocate the Unit and/or temporarily interrupt its operation, without liability to Tenant, as reasonably necessary to maintain and repair the roof or otherwise operate the Building.
Supplemental Services For requests for supplemental services relating to eBuyITT Invoice Processing by Service Receiver not mentioned in this Schedule or not included within the costs documented in this agreement, Service Receiver will provide a discreet project request and submit such request to Service Provider using the formalized Change Request attached as Annex A for consideration by Service Provider. Where notice is required a number of business days prior to some required action by Service Provider, notice must be received by 12 noon Eastern Time to be counted as received during such business day. Service Provider shall, within a commercially reasonable period, provide a price quote to be commercially reasonable based on the current cost of the Services to Service Receiver taking into account, such items as the specific time the request was made, service delivery volumes, exit planning activities, and other activities Service Provider is currently engaged in at the time of the request, but not later than 30 days after the request was made. If Service Provider, in its sole discretion determines (i) such request would increase the ongoing operating costs for Service Provider (as a service recipient) or any other service receiver or (ii) that it is not capable of making such changes with its current staff during the time period requested without interrupting the Services provided to itself or any other service receiver. Service Provider need not provide a price quote or perform the services. Where a price quote is provided, Service Provider shall provide the service requested upon acceptance of the price.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Return of Documents, Equipment, Etc All writings, records, and other documents and things comprising, containing, describing, discussing, explaining, or evidencing any Confidential Information, and all equipment, components, parts, tools, and the like in Executive’s custody or possession that have been obtained or prepared in the course of Executive’s employment with the Company shall be the exclusive property of the Company, shall not be copied and/or removed from the premises of the Company, except in pursuit of the business of the Company, and shall be delivered to the Company, without Executive retaining any copies, upon notification of the termination of Executive’s employment or at any other time requested by the Company. The Company shall have the right to retain, access, and inspect all property of Executive of any kind in the office, work area, and on the premises of the Company upon termination of Executive’s employment and at any time during employment by the Company to ensure compliance with the terms of this Agreement.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Specification Changes (a) During the Term, GSK will accept a labeling change from Prometheus as contemplated by this Section 4.2 but otherwise the Parties acknowledge and agree that GSK does not intend to make any material changes (such as packaging design, manufacturing process or similar or related changes) to the existing Product during the Term.
Term SOFR Conforming Changes In connection with the use or administration of Term SOFR, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document. The Administrative Agent will promptly notify the Borrower and the Lenders of the effectiveness of any Conforming Changes in connection with the use or administration of Term SOFR.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
