TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS Sample Clauses

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. ‌ a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌
AutoNDA by SimpleDocs
TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.

Related to TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS

  • Optional Xactimate Response Attachment (Part 2)

  • Purchase Order Requirements Customers shall use a Request for Quote per section 287.056(2), Florida Statutes, when making purchases off of this State Term Contract. Customers shall issue Request for Quotes to at least 25 vendors approved to provide IT Staff Augmentation services in accordance with section 287.0591(5), Florida Statutes. Customers shall order services from the Request for Quote via a Purchase Order with the Customers’ selected Contractor. The terms of the Purchase Order shall not conflict with the terms and conditions established by this Contract. In accepting a Purchase Order, the Contractor recognizes its responsibility for all tasks and deliverables contained therein, warrants that it has fully informed itself of all relevant factors affecting accomplishment of the tasks and deliverables and agrees to be fully accountable for the performance thereof.

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!