Temporary Schedule Changes Overtime-eligible employees’ workweeks and/or work schedules may be temporarily changed with prior notice from the Employer. A temporary schedule change is defined as a change lasting thirty (30) calendar days or less. With the exception of the job classifications listed in Appendix B, overtime-eligible employees will receive three (3) calendar days’ written notice of any temporary schedule change. The day that notification is given is considered the first day of notice. Adjustments in the hours of work of daily work shifts during a workweek do not constitute a temporary schedule change.
Temporary Services The steamfitters shall not do any other work and shall not be permitted to work more than one shift in a twenty- four hour day. When steamfitters are present during the regular working day, no temporary services steamfitter will be required. Effective Period: 7/1/2015 - 6/30/2016 Wage Rate per Hour: $41.80 Supplemental Benefit Rate per Hour: $42.76 Overtime Double time the regular rate after an 8 hour day. Double time the regular time rate for Saturday. Double time the regular rate for Sunday.
Temporary Structures Installation of temporary construction-related structures including scaffolding, barriers, screening, fences, protective walkways, signage, office trailers or restrooms.
Salary Schedule Progression Employees shall progress from step to step in salary grade on the basis of satisfactory job performance based upon established standards of performance. Seasonal employee's initial anniversary date shall be established after being in pay status for two thousand eighty (2,080) hours. Such date shall then be used for annual performance evaluation and step progression consideration. When an employee's anniversary date falls on any day from the first day of a pay week through Wednesday of the pay week, the employee's merit increase shall be effective as of the first day of the pay week within which the anniversary date falls. Otherwise, the merit increase shall be effective on the first day of the next pay week. Grievances arising from the denial of merit increases shall not be arbitrable under this Agreement but shall be processed as follows:
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Salary Schedule Placement 1. Credit hours for the purpose of placement on the salary schedule shall be defined as those semester hour credits earned for graduate courses that are within the teacher’s present certification or a planned program leading to additional areas of teacher certification, guidance or administration. Upon approval of the Superintendent, any other courses, graduate or undergraduate may be certified for proper placement on the salary schedule.
Permanent Schedule Changes Employees’ workweeks and work schedules may be permanently changed with prior notice from the Employer. Overtime-eligible employees will receive ten (10) calendar days’ written notice of a permanent schedule change. The day notification is given is considered the first day of notice. Notice will normally be given to the affected employees during their scheduled working hours. If an affected employee is on extended leave, notice may be sent to the employee’s last known address.
Temporary Suspension 13.1. JetBrains reserves the right to suspend Customer’s access to JetBrains Products if:
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
