Utility Service Tenant shall pay the cost of all utility services, including, but not limited to, initial connection charges and all charges for gas, water, and electricity used on the Leased Premises. If the Leased Premises are separately metered, Tenant shall pay such costs directly to the appropriate utility company. Otherwise, Tenant shall pay such costs pursuant to Paragraph 6(b) above. Tenant shall pay all costs caused by Tenant introducing excessive pollutants into the sanitary sewer system, including permits, fees and charges levied by any governmental subdivision for any pollutants or solids other than ordinary human waste. If Tenant can be clearly identified as being responsible for obstructions or stoppage of the common sanitary sewage line, the Tenant shall pay the entire cost thereof, upon demand, as additional rent. Tenant shall be responsible for the installation and maintenance of any dilution tanks, holding tanks, settling tanks, sewer sampling devices, sand traps, grease traps or similar devices which may be required by the appropriate governmental subdivision for Tenant's use of the sanitary sewer system. Tenant shall also pay all surcharges (i.e. charges in excess of normal charges) levied due to Tenant's abnormal use of sanitary sewer or waste removal services so that no such surcharges shall affect Landlord or other tenants in the Project under Paragraph 6(b) above.
Utility Services The Owner represents that, to the best of its knowledge, all utility services required to construct and operate the Project (including, without limitation, public water, sewer and electricity) are currently available to the Property in the capacities required to operate the Project. No work need be performed by or on behalf of the Developer to make such utilities available to the Property for the construction or operation of the Project, except for the matters, if any, set forth on Exhibit "D". Copies of letters from the providers of such utility services confirming such availability are annexed hereto as Exhibit "G".
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant’s Maintenance Subject to the provisions of Articles Fourteen and Fifteen, Tenant, at its expense, shall keep and maintain the Premises and all Tenant Additions thereto in good order, condition and repair and in accordance with all Laws and Environmental Laws. Tenant shall not permit waste and shall promptly and adequately repair all damages to the Premises and replace or repair all damaged or broken glass in the interior of the Premises, fixtures or appurtenances. Any repairs or maintenance shall be completed with materials of similar quality to the original materials, all such work to be completed under the supervision of Landlord. Any such repairs or maintenance shall be performed only by contractors or mechanics approved by Landlord, which approval shall not be unreasonably withheld, and whose work will not cause or threaten to cause disharmony or interference with Landlord or other tenants in the Building and their respective agents and contractors performing work in or about the Building. If Tenant fails to perform any of its obligations set forth in this Section 8.02, Landlord may, in its sole discretion and upon 48 hours prior notice to Tenant (but without notice in the case of emergencies), perform the same, and Tenant shall pay to Landlord any costs or expenses incurred by Landlord upon demand.
Electrical Service Subject to the limitation of this Paragraph 4, furnish electrical service to the Premises, including providing and installing all Building standard replacement lighting tubes. If Tenant uses more electrical power than Landlord in good faith considers reasonable or normal for office use, Tenant will pay Landlord on a monthly basis the cost of such excess power consumed by Tenant. Consumption will be determined, at Landlord’s election, either (a) by a survey performed by a reputable consultant selected by Landlord, or (b) through separate meters or submeters installed, maintained and read by Landlord at Tenant’s cost. For purposes of this Paragraph 4 only, “month” and “monthly” shall mean any billing period used by the utility or other power provider supplying electricity. All installations of electrical futures, appliances and equipment within the Premises shall be subject to Landlord’s prior approval, and if they affect the temperature or humidity otherwise maintained, Landlord may, at Tenant’s sole cost and expense (to be paid within (30) days after delivery of written demand supported by invoices or other reasonably satisfactory evidence), install supplemental air conditioning units. Tenant’s use of electricity shall never exceed Tenant’s share of the capacity of existing feeders to the Building or of the risers, wiring installations and transformers serving the floor(s) containing the Premises. Landlord shall provide up to 3.5 xxxxx per usable square foot (demand) of riser and floor panel electrical capacity averaged over the floor being serviced. EXHIBIT C Tenant shall be allocated an approximate 2.0 xxxxx per usable square foot for power and 1.5 xxxxx per usable square foot for lighting. Any risers or wiring necessary to meet Tenant’s excess electrical requirements will be installed by Landlord on Tenant’s request, at Tenant’s sole cost and expense (to be paid in advance), but only if in Landlord’s reasonable good faith belief they are necessary and will not cause damage to the Building or a dangerous condition, entail excessive or unreasonable alterations, repairs or expense, or disturb other occupants.
GOVERNMENT ENERGY OR UTILITY CONTROLS In the event of imposition of federal, state or local government controls, rules, regulations, or restrictions on the use or consumption of energy or other utilities during the Term, both Landlord and Tenant shall be bound thereby. In the event of a difference in interpretation by Landlord and Tenant of any such controls, the interpretation of Landlord shall prevail, and Landlord shall have the right to enforce compliance therewith, including the right of entry into the Premises to effect compliance.
Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.
Repairs; Maintenance (A) Landlord shall, subject to the need therefore not being caused in whole or part by the negligent or willful acts or omission of Tenant, its agents, employees, contractors or assigns, and subject to the aggregate cost thereof over the term not exceeding two (2) months of the then current Rent, maintain the exterior, structural walls, and foundations of the building except for alterations and improvements made by Tenant affecting the foregoing, which shall be Tenant’s responsibility to maintain and repair. Tenant shall throughout the Term, at no cost or expense to Landlord, make all other necessary repairs to the interior and exterior of the Premises, including, without limitation, the roof, the plumbing, the parking lot, mechanical and electrical systems serving the Premises. Tenant shall, in addition, at no cost or expense to Landlord, maintain the Premises, and all fixtures, equipment, Alternations and improvements installed or made by Tenant, by Landlord or any prior tenants contained therein, including, but not limited to, heating, air conditioning, water heater, water pump, plumbing (including sprinkler system), electrical and mechanical systems, in at least as good repair order and condition as the same are in on the Lease Commencement Date or date installed by Tenant, reasonable wear and tear and loss by fire or other casualty (to the extent this Lease is terminated pursuant to Section 21 and insurance proceeds sufficient to replace the same are paid to Landlord or its designee or unless Landlord elects, pursuant to Section 21, to restore the Premises), and promptly at no cost or expense to Landlord, shall make or cause to be made, all necessary repairs, interior and exterior, structural and non structural, foreseen as well as unforeseen. Tenant, at its own cost and expense shall also keep, maintain and repair all sideways, driveways, ground (including lawn care) and parking areas in a clean, neat and orderly condition and shall remove all snow and ice therefrom.
Continuous Improvement ACS will actively seek ways to enhance the process to improve effectiveness, efficiencies and quality. As desirable Service modifications and enhancements are identified, ACS or Customer may propose modifications to the project to change or enhance functionality. To maintain consistency, requests for modification will follow an established change control process as identified in Section 15 of the Agreement. VIII. Supporting Documents
Janitorial Service Landlord shall not be obligated to provide any janitorial services to the Premises or replace any light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises. Tenant shall be solely responsible, at Tenant’s sole cost and expense, for (i) performing all janitorial services, trash removal and other cleaning of the Premises, and (ii) replacement of all light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises, all as appropriate to maintain the Premises in a first-class manner consistent with the first-class nature of the Building and Project. Such services to be provided by Tenant shall be performed by contractors and pursuant to service contracts approved by Landlord. Tenant shall deposit trash as reasonably required in the area designated by Landlord from time to time. All trash containers must be covered and stored in a manner to prevent the emanation of odors into the Premises or the Project. Landlord shall have the right to inspect the Premises upon reasonable notice to Tenant and to require Tenant to provide additional cleaning, if necessary. In the event Tenant shall fail to provide any of the services described in this Section 6.6 to be performed by Tenant within five (5) days after notice from Landlord, which notice shall not be required in the event of an emergency, Landlord shall have the right to provide such services and any charge or cost incurred by Landlord in connection therewith shall be deemed Additional Rent due and payable by Tenant upon receipt by Tenant of a written statement of cost from Landlord.
