Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Multi-Tenant Floors If other tenants occupy space on the floor on which the Premises is located, Tenant’s identifying signage shall be provided by Landlord, at Tenant’s cost, and such signage shall be comparable to that used by Landlord for other similar floors in the Building and shall comply with Landlord’s then-current Building standard signage program.
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted
Tenant Repairs To repair, maintain and keep the Leased Premises and all trade fixtures and improvements therein in good and substantial repair subject only to defects in construction of the structural members of the Building, reasonable wear and tear and damage by fire, lightning and tempest or other casualty against which the Landlord is insured (herein collectively referred to as "Tenant Repair Exceptions"); and that the Landlord may enter and view state of repair and that the Tenant will repair according to notice in writing, except for Tenant Repair Exceptions and that the Tenant will leave the Leased Premises in good repair, except for Tenant Repair Exceptions. Notwithstanding anything hereinbefore contained, the Landlord may in any event make repairs to the Leased Premises without notice if such repairs are, in the Landlord's opinion, necessary for the protection of the Building and the Tenant covenants and agrees with the Landlord that if the Landlord exercises any such option to repair, the Tenant will pay to the Landlord together with the next instalment of Monthly Rent which shall become due after the exercise of such option all sums which the Landlord shall have expended in making such repairs and that such sums, if not so paid within such time, shall be recoverable from the Tenant as rent in arrears. Provided further that in the event that the Landlord from time to time makes any repairs as hereinbefore provided, the Tenant shall not be deemed to have been relieved from the obligation to repair and leave the Leased Premises in a good state of repair.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
