Tenant’s Risk Tenant agrees to use and occupy the Premises, and to use such other portions of the Building and the Project as Tenant is given the right to use by this Lease at Tenant’s own risk. The Landlord Parties shall not be liable to the Tenant Parties for any damage, injury, loss, compensation, or claim (including, but not limited to, claims for the interruption of or loss to a Tenant Party’s business) based on, arising out of or resulting from any cause whatsoever, including, but not limited to, repairs to any portion of the Premises or the Building or the Project, any fire, robbery, theft, mysterious disappearance, or any other crime or casualty, the actions of any other tenants of the Building or of any other person or persons, or any leakage in any part or portion of the Premises or the Building or the Project, or from water, rain or snow that may leak into, or flow from any part of the Premises or the Building or the Project, or from drains, pipes or plumbing fixtures in the Building or the Project. Any goods, property or personal effects stored or placed in or about the Premises shall be at the sole risk of the Tenant Party, and neither the Landlord Parties nor their insurers shall in any manner be held responsible therefor. The Landlord Parties shall not be responsible or liable to a Tenant Party, or to those claiming by, through or under a Tenant Party, for any loss or damage that may be occasioned by or through the acts or omissions of persons occupying adjoining premises or any part of the premises adjacent to or connecting with the Premises or any part of the Building or otherwise. Notwithstanding the foregoing, the Landlord Parties shall not be released from liability for any injury, loss, damages or liability to the extent arising from any gross negligence or willful misconduct of the Landlord Parties on or about the Premises; provided, however, in no event shall the Landlord Parties have any liability to a Tenant Party based on any loss with respect to or interruption in the operation of Tenant’s business. The provisions of this Section shall be applicable until the expiration or earlier termination of the Lease Term, and during such further period as Tenant may use or be in occupancy of any part of the Premises or of the Building.
Landlord’s Property All Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or placed in or about the Premises, from time to time, shall be at the sole cost of Tenant and shall be and become the property of Landlord; provided, however, Landlord may, by written notice to Tenant prior to the end of the Lease Term, or given following any earlier termination of this Lease, require Tenant, at Tenant’s expense, to remove any Alterations or improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, at Landlord’s election, to a building standard tenant improved condition as determined by Landlord; provided; however, that notwithstanding the foregoing, upon request by Tenant at the time of Tenant’s request for Landlord’s consent to any Alteration or improvement, Landlord shall notify Tenant whether the applicable Alteration or improvement will be required to be removed pursuant to the terms of this Section 8.5. If Tenant fails to complete such removal and/or to repair any damage caused by the removal of any Alterations or improvements in the Premises and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, if elected by Landlord, to a building standard tenant improved condition as determined by Landlord, prior to the expiration or earlier termination of this Lease, then Rent shall continue to accrue under this Lease in accordance with Article 16, below, after the end of the Lease Term until such work shall be completed, and Landlord shall have the right, but not the obligation, to perform such work and to charge the cost thereof to Tenant. Tenant hereby protects, defends, indemnifies and holds Landlord harmless from any liability, cost, obligation, expense or claim of lien, including but not limited to, court costs and reasonable attorneys’ fees, in any manner relating to the installation, placement, removal or financing of any such Alterations, improvements, fixtures and/or equipment in, on or about the Premises, which obligations of Tenant shall survive the expiration or earlier termination of this Lease.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above.
(b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01.
(c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,.
(d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions:
1. Actual cost of the Landlord Improvements: $100,000.00
2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75
(e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements:
(i) Replace all stained, damaged or missing ceiling tiles,
(ii) Paint all walls in the Leased Premises, the color to be designated by Tenant,
(iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C,
(iv) Shampoo all carpets in the office areas and hallways and
(v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use.
(vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface
(vii) Repair any existing alligator or pothole areas.
Tenant Repairs Except for those items for which Landlord is responsible by virtue of Section 4.02 below, Tenant shall, at its own cost and expense, clean, repair, maintain and replace the interior of the Premises and any improvements, equipment and fixtures therein, including without limitation all plate glass, lighting and other fixtures and equipment inside the Premises whether or not they were initially installed at Landlord's expense, and any HVAC, electrical and mechanical systems that service the Premises, so as to keep them in good operating condition and in compliance with the requirements from time to time of all governmental authorities having jurisdiction. All repairs, maintenance and/or replacements made by Tenant shall be subject to Landlord's prior written approval, which will not be unreasonably withheld provided that the same are at least equal in quality and class to the original work and/or fixtures and equipment. In the event that Tenant fails to make any necessary repairs, Landlord shall have the right, at its option, after providing written notice to Tenant, to perform on behalf of Tenant any repair or replacement approved by Landlord and one hundred five percent (105%) of the reasonable cost and expense incurred shall be due within thirty (30) days of demand. Landlord and Tenant agree that the Landlord will obtain a reasonable and customary maintenance, repair and service contract on the HVAC system serving the Premises, the cost of which shall be billed to Tenant and shall be deemed to be Additional Rent. The parties agree that, notwithstanding any provision of this Lease to the contrary, Tenant's obligation to pay for the maintenance, repair and replacement of the Building-standard systems (which includes the HVAC, sprinkler, electrical and plumbing systems) serving the Premises shall be limited to: (i) the cost of maintaining and making minor repairs to the Building-standard systems serving the Premises; (ii) the cost of the afore-mentioned service contract on the HVAC system; (iii) Tenant's Share of any such costs that are included in Operating Expenses; and (iv) the first $4,000.00 per year of the cost of major repairs or the cost of replacing such Building-standard systems serving the Premises. Tenant shall promptly place all of its refuse in the trash receptacles provided for this purpose and shall not allow same to accumulate within the Premises or anywhere on the Common Areas. It is understood and agreed that all property of Tenant kept, stored or maintained in the Premises or the Project shall be at the sole risk of Tenant. Tenant agrees at its sole cost and expense to comply with all present and future laws regarding the collection, sorting, separation and recycling of waste products, garbage, refuse and trash.
Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
Landlord’s Fees Whenever Tenant requests Landlord to take any action not required of it hereunder or give any consent required or permitted under this Lease, Tenant will reimburse Landlord for Landlord’s reasonable, out-of-pocket costs payable to third parties and incurred by Landlord in reviewing the proposed action or consent, including reasonable attorneys’, engineers’ or architects’ fees, within thirty (30) days after Landlord’s delivery to Tenant of a statement of such costs. Tenant will be obligated to make such reimbursement without regard to whether Landlord consents to any such proposed action.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
