Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Tenants Additional Covenants Tenant shall (a) join the Advisory Association and cooperate in the activities of such association; (b) at its election, engage in reasonable cross-marketing endeavors with the members of the Advisory Association; and (c) at its election, provide signage on the Property which references that the Property is owned by Landlord, which signage may include an appropriate logo selected by Landlord. In addition, it is the intent of the parties that Tenant be a single-purpose entity with no business operations except for those related solely to the operation of the Property for its Primary Intended Use and other property of Landlord which may be leased to Tenant. Tenant shall, therefore, not engage in or undertake any activities other than those respecting the operation of the Property for its Primary Intended Use, including leasing, managing, and operating golf courses in accordance with this Lease.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Additional Costs The Borrower shall promptly pay to the Agent for the account of a Lender from time to time such amounts as such Lender may determine to be necessary to compensate such Lender for any costs incurred by such Lender that it reasonably determines are attributable to its making, continuing, converting or maintaining of any LIBOR Rate Loans or its obligation to make any LIBOR Rate Loans hereunder (such amounts shall be based upon a reasonable allocation thereof by such Lender to any LIBOR Rate Loans made by such Lender hereunder), any reduction in any amount receivable by such Lender under this Agreement or any of the other Loan Documents in respect of any of such Loans or such obligation or the maintenance by such Lender of capital or liquidity in respect of its Loans or its Commitment (such increases in costs and reductions in amounts receivable being herein called “Additional Costs”), resulting from any Regulatory Change, and solely to the extent that such Lender generally imposes such Additional Costs on other similarly situated borrowers of such Lender in similar circumstances (to the extent such Lender has the right to do so), that: (i) changes the basis of taxation of any amounts payable to such Lender under this Agreement or any of the other Loan Documents in respect of any of such Loans or its Commitment (other than Excluded Taxes); or (ii) imposes or modifies any reserve, special deposit, liquidity or similar requirements (other than Regulation D of the Board of Governors of the Federal Reserve System or other reserve requirement to the extent utilized in the determination of the LIBOR Base Rate for such Loan) relating to any extensions of credit or other assets of, or any deposits with or other liabilities of, such Lender, or any commitment of such Lender (including, without limitation, the Commitments of such Lender hereunder); or (iii) has or would have the effect of reducing the rate of return on capital of such Lender to a level below that which such Lender could have achieved but for such Regulatory Change (taking into consideration such Lender’s policies with respect to capital adequacy and liquidity).
Payment of Additional Costs If termination of this contract is due to the failure of the Engineer to fulfill its contract obligations, the State may take over the project and prosecute the work to completion, and the Engineer shall be liable to the State for any additional cost to the State.
Additional Costs, Etc Notwithstanding anything herein to the contrary, if any present or future applicable law, which expression, as used herein, includes statutes, rules and regulations thereunder and interpretations thereof by any competent court or by any governmental or other regulatory body or official charged with the administration or the interpretation thereof and requests, directives, instructions and notices at any time (or from time to time) hereafter made upon or otherwise issued to any Lender or the Agent by any central bank or other fiscal, monetary or other authority (whether or not having the force of law), shall:
(a) subject any Lender or the Agent to any tax, levy, impost, duty, charge, fee, deduction or withholding of any nature with respect to this Agreement, the other Loan Documents, such Lender’s Commitment, a Letter of Credit or the Loans (other than taxes based upon or measured by the gross receipts, income or profits of such Lender or the Agent or its franchise tax), or
(b) materially change the basis of taxation (except for changes in taxes on gross receipts, income or profits or its franchise tax) of payments to any Lender of the principal of or the interest on any Loans or any other amounts payable to any Lender under this Agreement or the other Loan Documents, or
(c) impose or increase or render applicable any special deposit, reserve, assessment, liquidity, capital adequacy or other similar requirements (whether or not having the force of law and which are not already reflected in any amounts payable by the Borrower hereunder) against assets held by, or deposits in or for the account of, or loans by, or commitments of an office of any Lender, or
(d) impose on any Lender or the Agent any other conditions or requirements with respect to this Agreement, the other Loan Documents, the Loans, such Lender’s Commitment, a Letter of Credit or any class of loans or commitments of which any of the Loans or such Lender’s Commitment forms a part; and the result of any of the foregoing is:
(i) to increase the cost to any Lender of making, funding, issuing, renewing, extending or maintaining any of the Loans, the Letters of Credit or such Lender’s Commitment, or
(ii) to reduce the amount of principal, interest or other amount payable to any Lender or the Agent hereunder on account of such Lender’s Commitment or any of the Loans or the Letters of Credit, or
(iii) to require any Lender or the Agent to make any payment or to forego any interest or other sum payable hereunder, the amount of which payment or foregone interest or other sum is calculated by reference to the gross amount of any sum receivable or deemed received by such Lender or the Agent from the Borrower hereunder, then, and in each such case, the Borrower will, within fifteen (15) days of demand made by such Lender or (as the case may be) the Agent at any time and from time to time and as often as the occasion therefor may arise, pay to such Lender or the Agent such additional amounts as such Lender or the Agent shall determine in good faith to be sufficient to compensate such Lender or the Agent for such additional cost, reduction, payment or foregone interest or other sum. Each Lender and the Agent in determining such amounts may use any reasonable averaging and attribution methods generally applied by such Lender or the Agent.
Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.
Landlord’s Costs Tenant shall, within thirty (30) days after receipt of an invoice from Landlord, pay the reasonable costs, expenses, and fees of any architect or engineer employed by Landlord to review any plans and specifications and to supervise and approve any construction, or for any services rendered by such architect or engineer to Landlord as contemplated by any of the provisions of this Agreement, or for any services performed by Landlord's attorneys in connection therewith; provided, however, that Landlord will consult with Tenant and notify Tenant of the estimated amount of such expenses.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
