Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
TOTAL OR PARTIAL FAILURE TO PERFORM 20.1 In the case of Goods to be specially manufactured for it, if Transnet at any time ascertains that:
a) no manufacturing of the Goods specified in a Purchase Order has commenced and there is little or no prospect, in Transnet’s opinion, that manufacturing will commence within a reasonable time; or
b) delivery of any of the Goods is being or is likely to be delayed beyond the promised delivery date(s), and there is little or no prospect of the Purchase Order(s) being carried out within reasonable adherence to the promised delivery rate(s) or time(s), then Transnet may, irrespective of the cause of the delay, by notice to the Supplier, cancel as from a future date specified in such notice the whole or any part of this Agreement or Purchase Order in respect of which the Goods to be supplied have not been completed by that date, without incurring any liability by reason of such cancellation except as provided in this clause.
20.2 The Supplier/Service Provider shall thereupon, as soon as possible after such date, deliver to Transnet the Goods/Services [if any] already completed, and payment for the part performance shall be made on a pro rata basis, provided the uncompleted part is not an integral or essential part of the completed Goods/Services. Where an integral or essential part of the work has not been completed, the amount to be paid to the Supplier/Service Provider will be calculated on the basis of Transnet’s enrichment. The Supplier/Service Provider shall, wherever practicable, supply Transnet with the necessary drawings and/or specifications to enable it to complete the work.
20.3 Whenever, in any case not covered by clause 20.1 above, the Supplier fails or neglects to execute the work or to deliver any portion of the Goods/Services as required by the terms of this Agreement or Purchase Order, or if any Goods/Services are rejected on any of the grounds mentioned in clause Error! Reference source not found. [Defective Goods], Transnet may cancel this Agreement or Purchase Order in so far as it relates to the unexecuted work or the undelivered or rejected portion of the Goods/Services, and in such event, the supply of the remaining portion shall remain subject in all respects to these conditions.
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
Termination Due to Death If the Optionee’s employment terminates by reason of the Optionee’s death, any portion of this Stock Option outstanding on such date, to the extent exercisable on the date of death, may thereafter be exercised by the Optionee’s legal representative or legatee for a period of 12 months from the date of death or until the Expiration Date, if earlier. Any portion of this Stock Option that is not exercisable on the date of death shall terminate immediately and be of no further force or effect.
Termination Due to Death, Disability or Retirement In the event the Optionee’s employment or other service with the Company and all Subsidiaries is terminated by reason of death, Disability or Retirement, this Option will remain exercisable, to the extent exercisable as of the date of such termination, for a period of one year after such termination (but in no event after the Time of Termination).
Termination Due to Death or Disability The expiration of one (1) year from the date of the death of the Optionee or cessation of an Optionee’s employment or contractual relationship by reason of disability (as defined in Section 5.1(g) of the Plan). If an Optionee’s employment or contractual relationship is terminated by death, any Option held by the Optionee shall be exercisable only by the person or persons to whom such Optionee’s rights under such Option shall pass by the Optionee’s will or by the laws of descent and distribution.
Termination Due to Retirement Subject to Section 7 below, in the event of Termination due to Retirement, then (regardless of any subsequent death of the Employee) the Option will continue to vest pursuant to Section 3, and the last date on which the Option may be exercised is the day prior to the Expiration Date.
Termination After Change of Control In the event that, before the expiration of the TERM and in connection with or within one year of a CHANGE OF CONTROL (as defined hereinafter) of either one of the EMPLOYERS, (A) the employment of the EMPLOYEE is terminated for any reason other than JUST CAUSE before the expiration of the TERM, (B) the present capacity or circumstances in which the EMPLOYEE is employed is changed before the expiration of the TERM, or (C) the EMPLOYEE's responsibilities, authority, compensation or other benefits provided under this AGREEMENT are materially reduced, then the following shall occur:
(I) The EMPLOYERS shall promptly pay to the EMPLOYEE or to his beneficiaries, dependents or estate an amount equal to the sum of (1) the amount of compensation to which the EMPLOYEE would be entitled for the remainder of the TERM under this AGREEMENT, plus (2) the difference between (x) the product of three, multiplied by the total compensation paid to the EMPLOYEE for the immediately preceding calendar year as set forth on the Form W-2 of the EMPLOYEE, less (xx) the amount paid to the EMPLOYEE pursuant to clause (1) of this subparagraph (I);
(II) The EMPLOYEE, his dependents, beneficiaries and estate shall continue to be covered under all BENEFIT PLANS of the EMPLOYERS at the EMPLOYERS' expense as if the EMPLOYEE were still employed under this AGREEMENT until the earliest of the expiration of the TERM or the date on which the EMPLOYEE is included in another employer's benefit plans as a full-time employee; and
(III) The EMPLOYEE shall not be required to mitigate the amount of any payment provided for in this AGREEMENT by seeking other employment or otherwise, nor shall any amounts received from other employment or otherwise by the EMPLOYEE offset in any manner the obligations of the EMPLOYERS thereunder, except as specifically stated in subparagraph (II). In the event that payments pursuant to this subsection (ii) would result in the imposition of a penalty tax pursuant to Section 280G(b)(3) of the Internal Revenue Code of 1986, as amended, and the regulations promulgated thereunder (hereinafter collectively referred to as "SECTION 280G"), such payments shall be reduced to the maximum amount which may be paid under SECTION 280G without exceeding such limits.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions.
b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract.
(1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance.
(2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email.
(3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination.
c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.
