Termination for Default (Construction Sample Clauses

Termination for Default (Construction. If contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified, or any extension, or fails to complete the work within this time, or if contractor fails to comply with any other provisions of this contract, the recipient may terminate this contract for default. the recipient shall terminate by delivering to contractor a notice of termination specifying the nature of default. In this event, the recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. Contractor and its sureties shall be liable for any damage to the recipient resulting from contractor's refusal or failure to complete the work within specified time, whether or not contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the recipient in completing the work. Contractor's right to proceed shall not be terminated nor shall contractor be charged with damages under this clause if: 1. Delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of contractor. Examples of such causes include: acts of God, acts of the recipient, acts of another contractor in the performance of a contract with the recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. Contractor, within 10 days from the beginning of any delay, notifies the recipient in writing of the causes of delay. If in the recipient’s judgment, delay is excusable, the time for completing the work shall be extended. The recipient’s judgment shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of contractor's right to proceed, it is determined that contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if termination had been issued for the recipient’s convenience.
Sample 1Sample 2Sample 3See All (40)
AutoNDA by SimpleDocs
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the (Recipient) may terminate this contract for default. The (Recipient) shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the Recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if-
Sample 1Sample 2See All (4)
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, GLPTC may terminate this contract for default. GLPTC shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, GLPTC may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to GLPTC resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by GLPTC in completing the work. 1. the delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of GLPTC, acts of another Contractor in the performance of a contract with GLPTC, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. the Contractor, within ten (10) days from the beginning of any delay, notifies in writing of the causes of delay. If in the judgment of GLPTC, the delay is excusable, the time for completing the work shall be extended. The judgment of GLPTC shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of GLPTC.
Sample 1
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the county may terminate this contract for default. The County shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the County may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the County resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the County in completing the work. The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause if: a. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault of negligence of the Contractor. Examples of such causes include: acts of God, acts of the County, acts of another Contractor in the performance of a contract with the County, epidemics, quarantine restrictions, strikes, freight embargoes; and b. The Contractor, within ten (10) days from the beginning of any delay, notifies the County in writing of the causes of delay. If, in the judgement of the County, the delay is excusable, the time for completing the work shall be extended. The judgement of the County shall be final and conclusive on he parties, but subject to appeal under Dispute clauses (FTA clauses vs contract clauses…read and firm up).
Sample 1
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this Contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this Contract, the City may terminate this Contract for default. The City shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the City may take over the work and compete it by Contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if-
Sample 1
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, NYCDOT may terminate this contract for default. NYCDOT shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, NYCDOT may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to NYCDOT resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by NYCDOT in completing the work.
Sample 1
Termination for Default (Construction. Section 80-09 of FAA Advisory Circular 150/5370-10 establishes conditions, rights, and remedies associated with Owner termination of this contract due to default of the Contractor.
Sample 1
AutoNDA by SimpleDocs
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will ensure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provision of this contract, City may terminate this contract for default. The City shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the City may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the City resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the City in completing the work. The Contractor's right to proceed shall not be terminated nor shall the Contractor be charged with damages under this clause if: 1. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of City, acts of another contractor in the performance of a contract with City, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. The Contractor, within
Sample 1

Related to Termination for Default (Construction

  • Termination for Default; Remedies 8.2.1 Each of the following shall constitute an immediate event of default (“Event of Default”) under this Agreement: (a) Contractor fails or refuses to perform or observe any term, covenant or condition contained in any of the following Sections of this Agreement:

  • Termination for Default The Commonwealth may terminate this Agreement by notice where it reasonably believes the Grantee: (a) has breached this Agreement; or (b) has provided false or misleading statements in their application for the Grant; or (c) has become bankrupt or insolvent, entered into a scheme of arrangement with creditors, or come under any form of external administration.

  • SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.

  • Default Remedies Termination If the Stop Work Order is canceled, ODHS may, after receiving and evaluating a request by the Contractor, make an adjustment in the time required to complete this Contract and the Contract price by a duly executed amendment.

  • Erroneous Termination for Default If, after notice of termination of Vendor’s right to proceed under the provisions of this clause, it is determined for any reason that the contract was not in default, or that the delay was excusable under the provisions of the prior paragraph (Excuse for Nonperformance or Delayed Performance), the rights and obligations of the parties shall be the same as if the notice of termination had been one of termination for convenience.

  • Performance Default and Remedies Subsection B. DEFAULT AND REMEDIES, second paragraph of the Contract is modified as follows (underlined language is added and stricken language is deleted): “Written notice of default and a reasonable 30-day opportunity to cure must be issued by the party claiming default.”

  • Termination Remedies (a) If all conditions precedent to the obligations of Buyer set forth in Article VII, or of Seller set forth in Article VIII, (such Party that has satisfied its conditions precedent, the “Performing Party”) have been met and the transactions contemplated by this Agreement are not consummated on or before the Closing Date because of the failure of Buyer or Seller to perform any of its material obligations hereunder or the breach of any representation herein by Buyer or Seller (such party that has not satisfied its conditions precedent, the “Breaching Party”) and the Performing Party has performed all of its material obligations hereunder and has not breached any representation herein, then in such event, the Performing Party shall have the option to terminate this Agreement, in which case (i) if Buyer is the Breaching Party, Seller shall retain the Deposit as liquidated damages on account of Buyer’s failure to perform its obligations under this Agreement or Buyer’s breach of any representation under this Agreement, which remedy shall be the sole and exclusive remedy available to Seller for Buyer’s breaches or (ii) if Seller is the Breaching Party, then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after receipt of Buyer’s notice of termination. Buyer and Seller acknowledge and agree that (i) the Seller’s actual damages upon the event of such a termination are difficult to ascertain with any certainty, (ii) that the Deposit is a reasonable estimate of such actual damages and (iii) such liquidated damages do not constitute a penalty. Additionally, if Seller is the Breaching Party, in lieu of terminating this Agreement, Buyer shall have the right of specific performance of this Agreement. (b) If this Agreement is terminated for any reason, other than as set forth in Section 11.03(a), then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after the event giving rise to such payment to Buyer. Buyer and Seller shall thereupon have the rights and obligations set forth elsewhere herein.

  • CANCELLATION FOR DEFAULT In the event Contractor is in default of any of its obligations under the Contract, Con Edison shall have the right, on written notice to Contractor and any sureties, to cancel the Contract for default. Contractor shall be deemed to be in default hereunder if it is in default of any of its obligations under the Contract or makes any statement or performs any act indicating that it will not perform one or more of such obligations (whether or not the time has yet arrived for performance thereof) or rejects the Contract under the United States Bankruptcy Code or ceases to pay its debts promptly or becomes insolvent or commences or has commenced against it any insolvency proceeding or finds its affairs placed in the hands of a receiver, trustee, or assignee for the benefit of creditors. In the event of cancellation for default hereunder, Article 33 (Termination for Convenience), shall not apply, and Con Edison shall have all rights and remedies provided by law and the Contract. Without intending to limit the generality of the foregoing, it is specifically understood and agreed that Con Xxxxxx shall have the right, at its election and without prejudice to any other remedies, (i) to exclude Contractor from the construction site, or any portion of the construction site, (ii) to complete or employ a third party to complete the Work or any portion of the Work, and hold Contractor liable for any additional cost occasioned thereby, (iii) to take possession of any or all materials, tools, equipment and appliances at the construction site for the purpose of completing the Work or any portion of the Work, (iv) to compel Contractor to assign any or all subcontracts with Subcontractors to Con Edison without additional cost or expense to Con Edison, and/or (v) to negotiate new contractual arrangements with Subcontractors for such Subcontractors to complete all or any portion of the work on terms agreeable to Con Edison. Upon Con Xxxxxx's request, Contractor shall promptly provide Con Xxxxxx with Contractor's sworn statement stating, for each subcontract with each Subcontractor (i) the original price of the subcontract and the price of each change order thereunder together with a description of each such change order, (ii) the amount that Contractor paid under the subcontract and each change order thereunder, and (iii) the amount of retention held by Contractor under the subcontract and each change order thereunder. Following cancellation of the Contract for default, Contractor shall not be entitled to any further payment until the work has been fully completed and accepted, and Con Edison may retain from any money otherwise due Contractor for services rendered prior to cancellation an amount which Con Edison determines is adequate to cover all damage resulting from Contractor's default. If such costs and damages exceed the unpaid balance, Contractor shall pay the difference to Con Xxxxxx. Upon cancellation for default of the Contract under this Article, Con Edison shall be entitled to cancel for default any or all other contracts between the Contractor and Con Edison, and such cancellation shall be governed by this Article. Also, a cancellation for default of any other contract between Contractor and Con Edison shall entitle Con Edison to cancel for default the Contract under this Article. In the event that Contractor demonstrates that a cancellation of the Contract and any other contract cancelled for default is erroneous, the cancellation shall, at Con Edison's option, be withdrawn or be deemed to have been issued as a termination for convenience pursuant to Article 33, and the rights and obligations of the parties hereto shall in such event be governed accordingly.

  • Event of Default Remedies 8.1 Any one or more of the following acts or omissions of the Contractor shall constitute an event of default hereunder (“Event of Default”): 8.1.1 failure to perform the Services satisfactorily or on schedule; 8.1.2 failure to submit any report required hereunder; and/or 8.1.3 failure to perform any other covenant, term or condition of this Agreement. 8.2 Upon the occurrence of any Event of Default, the State may take any one, or more, or all, of the following actions: 8.2.1 give the Contractor a written notice specifying the Event of Default and requiring it to be remedied within, in the absence of a greater or lesser specification of time, thirty (30) days from the date of the notice; and if the Event of Default is not timely cured, terminate this Agreement, effective two (2) days after giving the Contractor notice of termination; 8.2.2 give the Contractor a written notice specifying the Event of Default and suspending all payments to be made under this Agreement and ordering that the portion of the contract price which would otherwise accrue to the Contractor during the period from the date of such notice until such time as the State determines that the Contractor has cured the Event of Default shall never be paid to the Contractor; 8.2.3 give the Contractor a written notice specifying the Event of Default and set off against any other obligations the State may owe to the Contractor any damages the State suffers by reason of any Event of Default; and/or 8.2.4 give the Contractor a written notice specifying the Event of Default, treat the Agreement as breached, terminate the Agreement and pursue any of its remedies at law or in equity, or both.

  • Termination and Default Either party, upon determination that the other party has failed or refused to perform or is otherwise in breach of any obligation or provision under this Agreement or the Contract Document, may give written notice of default to the defaulting party in the manner specified for the giving of notices herein. Termination of this Agreement by either party for any reason shall have no effect upon the rights or duties accruing to the parties prior to termination.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!