TERMINATION OF THE PROJECT AGREEMENT Sample Clauses

TERMINATION OF THE PROJECT AGREEMENT. 22.1 Should the Lead Council become entitled to terminate the Project Agreement or otherwise serve a notice pursuant to Clause 67 (Termination for Contractor Default), Clause 69 (Termination on Force Majeure), Clause 71 (Termination on Corrupt Gifts and Fraud) and Clause 75 (Termination for Breach of the Refinancing Provisions) of the Project Agreement, the Councils shall meet as soon as reasonably practicable thereafter to decide as a Matter Reserved To The Councils whether the Project Agreement should be terminated (and for the avoidance of doubt no partial termination is contemplated, any changes of scope in the Project to be addressed as an Authority Change), taking into account: 22.1.1 the point during the Project term at which termination of the Project Agreement would occur; 22.1.2 the financial consequences of such termination and the rights of the Contractor pursuant to Schedule 17 (Compensation on Termination) of the Project Agreement; 22.1.3 the financial consequences of continuing with the Project; 22.1.4 the views of each Council concerning such termination; 22.1.5 any alternative providers or means of provision of the works and/or services available to the Lead Council (and the other Councils); 22.1.6 whether the Councils are required to step in to provide the works and/or services; and 22.1.7 any other matters relevant to the termination or continuance of the Project. 22.2 For the avoidance of doubt, the Lead Council shall not be entitled to issue a notice of voluntary termination in accordance with Clause 73 (Voluntary Termination by the Authority) of the Project Agreement unless such action has been approved by all of the Councils as a Matter Reserved To The Councils.
AutoNDA by SimpleDocs
TERMINATION OF THE PROJECT AGREEMENT. The Project Agreement and all obligations of the parties under the Project Agreement shall forthwith terminate upon: (i) full payment of the Withdrawn Loan Balance and all other Loan Payments due; or (ii) when all obligations of the Co-financing Agreement have been fully performed, whichever is later.” 1.02. Unless the context requires otherwise, the capitalized terms used in the Project Agreement have the meanings ascribed to them in the Loan Agreement or the General Conditions and the following terms have the following meanings:
TERMINATION OF THE PROJECT AGREEMENT extension of the Contract for a further five (5) years in accordance with the terms of the Project Agreement;
TERMINATION OF THE PROJECT AGREEMENT. 17 ARTICLE X MISCELLANEOUS 17
TERMINATION OF THE PROJECT AGREEMENT. Section 2.01. The Project Agreement is hereby terminated and the rights and obligations of the parties thereto shall cease and determine on the date of effectiveness of this Agreement.

Related to TERMINATION OF THE PROJECT AGREEMENT

  • Termination of the Lease The parties agree that the Management Agreement and the rights and benefits of Manager thereunder shall not be terminated or disturbed in any respect except in accordance with the terms of the Management Agreement, and not as a result of any termination of the Lease. Accordingly, if the Lease is terminated for any reason, including, without limitation, expiration of the term thereof or the "rejection" thereof following Bankruptcy (a) shall recognize Manager's rights under the Management Agreement, (b) agrees that Manager shall not be named as a party in any eviction or other possessory action or proceeding, and that Manager shall not be disturbed in its right to manage the Inn pursuant to the Management Agreement, and (c) shall at the time of or prior to such Lease Termination either (i) elect not to take either of the actions described in clause (c)(ii) below, in which case all of "Lessee's" rights, benefits, privileges and obligations under the Management Agreement with respect to periods after the Lease Termination shall be assumed directly by Lessor, or (ii) cause an "Approved Lessee" (as defined below) to (x) succeed to and assume Lessee's rights and obligations under the Lease, the Management Agreement, and this Agreement, or (y) enter into a new lease with Lessor in substantially the same form as the Lease, and assume the rights and obligations of the Lessee under the Management Agreement and this Agreement, the intent being that the relationship between any successor Lessee, Lessor and Manager be under the same terms and conditions as the relationship between Lessee, Lessor and Manager hereunder and under the Management Agreement and the Lease. Any successor to Lessee under clause (c)(ii) above shall be subject to Manager's prior written approval, which approval shall not be withheld or delayed if such successor to Lessee is (i) a direct or indirect wholly-owned subsidiary of Lessor, (ii) a person or entity to whom a Sale of the Inn is permitted under Section 10.02.A. of the Management Agreement, or (iii) a person or entity who otherwise is approved by Manager in its sole discretion (an "Approved Lessee").

  • COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.

  • COMPLETION OF AGREEMENT This document comprises the entire agreement between the District and the Association in the matters lawfully within the scope of negotiation. Neither party shall have any obligation to meet and negotiate during the term of this agreement.

  • Completion of the Project The Participating County acknowledges it is obligated to undertake and complete the design and construction of the Project in compliance with all of the applicable terms and conditions of the Project Documents and the Participating County agrees to use its best efforts to cause the completion of design and construction of the Project in compliance with the applicable terms and conditions of such documents. The Participating County agrees to complete the Project in accordance with this Agreement and consistent with the scope, cost and schedule established by the Board and attached hereto in Exhibit A, as such scope, cost and schedule may be modified with the approval of Finance and the recognition of the Board.

  • Execution of the Project (a) The Recipient declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through its MoE with due diligence and efficiency and in conformity with appropriate financial, economic, environmental and administrative practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project. (b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Recipient and the Association shall otherwise agree, the Recipient shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement. (a) Except as the Association shall otherwise agree, procurement of the goods, works and consultants’ services required for the Project and to be financed out of the proceeds of the Grant shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan. (b) The Recipient shall update the Procurement Plan in accordance with terms of reference acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval. Section 3.03. Without limitation upon any of its obligations under paragraph (a) of Section 3.01 of this Agreement and except as the Recipient and the Association shall otherwise agree, the Recipient shall: (i) not later than by the effectiveness of this Agreement open a separate project account (the Project Account) in a commercial bank acceptable to the Association; (ii) thereafter maintain the Project Account during the entire Project implementation period, and replenish said Account regularly with funds sufficient to ensure the Recipient’s Project co-financing obligations; and (iii) use the amount in the Project Account exclusively for financing the Recipient’s contribution to Project expenditures. Section 3.04. For the purposes of Section 6.09 of the General Conditions and without limitation thereto, the Recipient shall: (a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Recipient and the Association, a plan designed to ensure the continued achievement of the Project’s objectives; and (b) afford the Association a reasonable opportunity to exchange views with the Recipient on said plan.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • Construction of this Agreement The Parties agree that each Party and its legal counsel have reviewed and revised this Agreement and that any rule of construction to the effect that ambiguities are to be resolved against the drafting Party shall not apply in the interpretation of this Agreement or any amendments or exhibits thereto.

  • Termination of this Agreement Prior to the Closing Date, this Agreement may be terminated by the Representatives by notice given to the Company if at any time: (i) trading or quotation of any of the Company’s securities shall have been suspended or limited by the Commission or by the New York Stock Exchange (the “NYSE”), or trading in securities generally on either the Nasdaq Stock Market or the NYSE shall have been suspended or limited, or minimum or maximum prices shall have been generally established on any of such quotation system or stock exchange by the Commission or FINRA; (ii) a general banking moratorium shall have been declared by any of federal, New York or Washington authorities; (iii) there shall have occurred any outbreak or escalation of national or international hostilities or any crisis or calamity, or any change in the United States or international financial markets, or any substantial change or development involving a prospective substantial change in United States’ or international political, financial or economic conditions, as in the judgment of the Representatives is material and adverse and makes it impracticable or inadvisable to proceed with the offering sale or delivery of the Securities in the manner and on the terms described in the Pricing Disclosure Package or to enforce contracts for the sale of securities; (iv) in the judgment of the Representatives there shall have occurred any Material Adverse Change; or (v) the Company shall have sustained a loss by strike, fire, flood, earthquake, accident or other calamity of such character as in the judgment of the Representatives may interfere materially with the conduct of the business and operations of the Company regardless of whether or not such loss shall have been insured. Any termination pursuant to this Section 10 shall be without liability on the part of (x) the Company to any Initial Purchaser, except that the Company shall be obligated to reimburse the expenses of the Initial Purchasers pursuant to Sections 4 and 6 hereof, (y) any Initial Purchaser to the Company, or (z) any party hereto to any other party except that the provisions of Sections 8 and 9 hereof shall at all times be effective and shall survive such termination.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!