THE OWNER’S ELECTION Sample Clauses

THE OWNER’S ELECTION. 8.5.3.1 The Owner may elect mediation at any time, regardless of whether arbitration or judicial proceedings have been commenced, and the Owner’s commencement of or participation in such arbitration or judicial proceedings shall not waive the Owner’s right to later elect mediation. 8.5.3.2 The Owner may elect arbitration at any time, regardless of whether the Owner has previously elected mediation or whether judicial proceedings have been commenced, and the Owner’s commencement of or participation in such mediation or judicial proceedings shall not waive the Owner’s right to later elect arbitration. 8.5.3.3 The Architect may not commence any judicial proceedings against the Owner without first offering the Owner the opportunity to initially elect mediation or arbitration by notifying the Owner in writing of the nature of the dispute, the factual basis for its claims, and the amount or other relief claimed. If the Owner does not make its election within thirty (30) days after such notice, the Architect may proceed to resolve such dispute through judicial proceedings. The Owner’s failure to elect mediation or arbitration within such thirty (30) day period shall not, however, waive the Owner’s right to later elect mediation or arbitration. 8.5.3.4 Except as provided in paragraphs 8.4.3.1 through 8.4.3.3, in the absence of the Owner’s election for mediation or arbitration, the parties shall have the right to resolve their disputes under the Agreement through judicial proceedings. 8.5.3.5 With respect to any “judicial proceedings” by and between the parties, it is hereby agreed that they shall be commenced only in: (a) the Complex Commercial Litigation Division of the Superior Court of New Castle County, Delaware; or (b) in default of subject matter jurisdiction therein, in the Superior Court of New Castle, County, Delaware; or (c) in the United States District Court for the District of Delaware, and the parties do hereby consent to both personal jurisdiction and venue in and to proceedings brought in any such court which has competent subject matter jurisdiction. TO THE EXTENT PERMITTED BY LAW, IT IS MUTUALLY AGREED BY AND BETWEEN THE OWNER AND THE ARCHITECT THAT THE RESPECTIVE PARTIES HERETO SHALL, AND THEY DO HEREBY, WAIVE TRIAL BY JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM BROUGHT BETWEEN THE PARTIES HERETO OR THEIR SUCCESSORS OR ASSIGNS ON ANY MATTERS ARISING OUT OF, OR IN ANY WAY CONNECTED WITH, THIS AGREEMENT OR THE PROJECT. In the event of any contr...
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs

Related to THE OWNER’S ELECTION

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.

  • SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO. 4.2 The Authority reserves the right (acting reasonably) to specify that the MI Report be submitted by the Supplier using an alternative communication to that specified in paragraph 4.1 above such as email. The Supplier agrees to comply with any such instructions provided they do not materially increase the burden on the Supplier.

  • Transfer of Servicing Between Master Servicer and Special Servicer; Record Keeping (a) Upon determining that any Serviced Loan has become a Specially Serviced Loan, the Master Servicer shall promptly give written notice thereof to the Special Servicer, any related Serviced Companion Loan Holder (in the case of a Serviced Loan Combination), the Operating Advisor, the Certificate Administrator, the Trustee, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and shall promptly deliver a copy of the Servicing File to the Special Servicer and concurrently provide a copy of such Servicing File to the Operating Advisor and shall use its reasonable efforts to provide the Special Servicer with all information, documents (but excluding the original documents constituting the Mortgage File, but including copies thereof) and records (including records stored electronically on computer tapes, magnetic discs and the like) relating to such Serviced Loan and reasonably requested by the Special Servicer to enable it to assume its duties hereunder with respect thereto without acting through a Sub-Servicer. The Master Servicer shall use its reasonable efforts to comply with the preceding sentence within five (5) Business Days of the date such Serviced Loan became a Specially Serviced Loan and in any event shall continue to act as Master Servicer and administrator of such Serviced Loan until the Special Servicer has commenced the servicing of such Serviced Loan, which shall occur upon the receipt by the Special Servicer of the Servicing File. With respect to each such Serviced Loan that becomes a Specially Serviced Loan, the Master Servicer shall instruct the related Mortgagor to continue to remit all payments in respect of such Serviced Loan to the Master Servicer. The Master Servicer shall forward any notices it would otherwise send to the Mortgagor of such a Specially Serviced Loan to the Special Servicer who shall send such notice to the related Mortgagor. Upon determining that a Specially Serviced Loan has become a Corrected Loan, the Special Servicer shall promptly give written notice thereof to the Master Servicer, the Trustee, the Operating Advisor, the Certificate Administrator, any related Serviced Companion Loan Holder, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and, upon giving such notice and the return of the Servicing File to the Master Servicer, such Serviced Loan shall cease to be a Specially Serviced Loan in accordance with the first proviso of the definition of Specially Serviced Loans, the Special Servicer’s obligation to service such Serviced Loan shall terminate and the obligations of the Master Servicer to service and administer such Serviced Loan as a Serviced Loan that is not a Specially Serviced Loan shall resume. In addition, if the related Mortgagor has been instructed, pursuant to the preceding paragraph, to make payments to the Special Servicer, upon such determination, the Special Servicer shall instruct the related Mortgagor to remit all payments in respect of such Specially Serviced Loan directly to the Master Servicer. (b) In servicing any Specially Serviced Loan, the Special Servicer shall provide to the Custodian originals of documents included within the definition of “Mortgage File” for inclusion in the related Mortgage File (to the extent such documents are in the possession of the Special Servicer) and copies of any additional related Serviced Loan information, including correspondence with the related Mortgagor, and the Special Servicer shall promptly provide copies of all of the foregoing to the Master Servicer as well as copies of any analysis or internal review prepared by or for the benefit of the Special Servicer. (c) Notwithstanding the provisions of subsections (a) and (b) of this Section 3.22, the Master Servicer shall maintain ongoing payment records with respect to each of the Specially Serviced Loans and, upon request, shall provide the Special Servicer and the Operating Advisor with any information reasonably required by the Special Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Master Servicer’s possession. Upon request, the Special Servicer shall provide the Master Servicer and the Operating Advisor with any information reasonably required by the Master Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Special Servicer’s possession.

  • INSTRUCTIONS FOR COMPLETING REPAYMENT ELECTION FORM AND EXERCISING REPAYMENT OPTION Capitalized terms used and not defined herein have the meanings defined in the accompanying Repayment Election Form.

  • Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history.

  • DIRECTORS’ STATEMENT The Board of Directors of Hua-An, having considered all aspect of the Proposed Acquisition, is of the opinion that the execution of the Proposed Acquisition in the best interests of Hua-An.

  • Attachment  C_ CONTRACT AFFIRMATIONS For purposes of these Contract Affirmations, HHS includes both the Health and Human Services Commission (HHSC) and the Department of State Health Services (DSHS). System Agency refers to HHSC, DSHS, or both, that will be a party to this Contract. These Contract Affirmations apply to all Contractors and Grantees (referred to as “Contractor”) regardless of their business form (e.g., individual, partnership, corporation). By entering into this Contract, Contractor affirms, without exception, understands, and agrees to comply with the following items through the life of the Contract:

  • Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

  • Final Acceptance All Work has been completed and accepted by the County. The Contractor has provided all required close-out documentation and items as required by the Detailed Scope of Work for the specific Job Order, and these items and have accepted and approved by the County

  • Written Election At the time you make a rollover or conversion to a Xxxx XXX, you must designate in writing to the custodian your election to treat that contribution as a rollover or conversion. Once made, the election is irrevocable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!