Time Limit and other Requirements for Contractor’s Notice of Claim, and Waiver of Claim Sample Clauses

Time Limit and other Requirements for Contractor’s Notice of Claim, and Waiver of Claim. The Contractor’s written notice of Claim shall set forth: (i) the reasons for which the Contractor believes additional compensation or increase in the Contract Price will or may be due or additional Contract Time should be granted; (ii) the nature of the costs involved; (iii) Contractor’s plan for mitigating such costs; (iv) if reasonably ascertainable, the amount of the potential Claim; (v) if the Contractor’s Claim relates to or will affect the critical path of the Project Schedule, demonstrable proof of such; and (vi) Contractor’s plan for mitigating any such delay. Time is expressly of the essence with respect to Contractor’s giving of notice of any Claim or potential Claim to Princeton University as specified in this Contract, so as to provide Princeton University an opportunity to remedy any breach or to take action to avoid or mitigate any cause for any cost increases or escalation or delay to the performance of the Work. It is an express condition precedent to Contractor’s ability to pursue any Claim for increase in the Contract Price or extension of Contract Time or any Claim for damages against Princeton University or the Project or any remedy whatsoever relating to the Contract, that Contractor deliver to Princeton University the written notice in compliance with Clauses J3(b) and J3(c), within five (5) business days after the date on which the Contractor has knowledge, or should reasonably have knowledge, of the events or circumstances giving rise to such Claim or potential right to Claim. If Contractor does not provide the written notice within the time required and otherwise in strict conformance with the requirements of Clauses J3(b) and J3(c) and any other applicable terms of the Contract, Contractor shall have conclusively and expressly waived such Claim or any potential right to Claim and/or any ability to pursue any remedies for the subject matter of such Claim or potential right to Claim and Contractor shall be forever estopped from asserting otherwise. CLAUSE J4 DISPUTE RESOLUTION
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs

Related to Time Limit and other Requirements for Contractor’s Notice of Claim, and Waiver of Claim

  • Waiver of Claims 9.1. The CONTRACTOR's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the CITY arising out of this Agreement or otherwise related to the Project, except those previously made in writing and identified by the CONTRACTOR as unsettled at the time of the final payment. Neither the acceptance of the CONTRACTOR's services nor payment by the CITY shall be deemed to be a waiver of any of the CITY's rights against the CONTRACTOR.

  • Release and Waiver of Claims In consideration of the severance payments and other benefits to which I have become entitled, pursuant to that certain letter agreement between Corsair Memory, Inc., a Delaware corporation (the “Company”), and myself dated , 20 (the “Severance Agreement”), in connection with the termination of my employment, I, , hereby furnish the Company with the following release and waiver (“Release and Waiver”). I hereby release and forever discharge the Company, its officers, directors, agents, employees, stockholders, successors, assigns and affiliates from any and all claims, liabilities, demands, causes of action, costs, expenses, attorney fees, damages, indemnities and obligations of every kind and nature, in law, equity or otherwise, known and unknown, suspected and unsuspected, disclosed and undisclosed, arising from or relating to my employment with the Company and the termination of that employment, including (without limitation) claims of wrongful discharge, emotional distress, defamation, fraud, breach of contract, breach of the covenant of good faith and fair dealing, discrimination claims based on sex, age, race, national origin, disability or any other basis under Title VII of the Civil Rights Act of 1964, as amended, the California Fair Employment and Housing Act, the Federal Age Discrimination in Employment Act of 1967, as amended (“ADEA”), the Americans with Disability Act, contract claims, tort claims, and wage or benefit claims, including but not limited to, claims for salary, bonuses, commissions, stock grants, stock options, vacation pay, fringe benefits, severance pay or any other form of compensation (other than the severance payments and benefits to which I am, pursuant to the express provisions of the Severance Agreement, entitled in connection with my termination of employment, my vested rights under the Company’s Section 401(k) Plan and any worker’s compensation benefits under any Company workers’ compensation insurance policy or fund). In releasing claims unknown to me at present, I am waiving all rights and benefits under Section 1542 of the California Civil Code, and any law or legal principle of similar effect in any jurisdiction: “A general release does not extend to claims which the creditor does not know or suspect to exist in his favor at the time of executing the release, which if known by him must have materially affected his settlement with the debtor.” This Release and Waiver does not pertain to any claims which may subsequently arise in connection with the Company’s default in any severance payment obligations under the Severance Agreement. I acknowledge that, among other rights subject to this Release and Waiver, I am hereby waiving and releasing any rights I may have under ADEA, that this release and waiver is knowing and voluntary, and that the consideration given for this release and waiver is in addition to anything of value to which I was already entitled as an executive of the Company. I further acknowledge that I have been advised, as required by the Older Workers Benefit Protection Act, that: (a) the release and waiver granted herein does not relate to claims which may arise after this release and waiver is executed; (b) I have the right to consult with an attorney prior to executing this release and waiver (although I may choose voluntarily not to do so); and if I am over 40 years old upon execution of this; (c) I have twenty-one (21) days from the date of termination of my employment with the Company in which to consider this release and waiver (although I may choose voluntarily to execute this release and waiver earlier); (d) I have seven (7) days following the execution of this release and waiver to revoke my consent to this release and waiver; and (e) this release and waiver shall not be effective until the seven (7)-day revocation period has expired. Date: Signature: Print Name:

  • Waiver of Claim for Attorney’s Fees The defendant waives all of his claims under the Hyde Amendment, 18 U.S.C. § 3006A, for attorney’s fees and other litigation expenses arising out of the investigation or prosecution of this matter.

  • Certification of claims by Statutory Auditors Any claim or document provided by the Concessionaire to the Authority in connection with or relating to receipts, income, payments, costs, expenses, accounts or audit, and any matter incidental thereto shall be valid and effective only if certified by its Statutory Auditors. For the avoidance of doubt, such certification shall not be required for exchange of information in the normal course of business including the submission of Monthly Fee Statements under Clause 19.5.

  • Waiver of FOIA Request The defendant waives all of his rights, whether asserted directly or by a representative, to request or receive from any department or agency of the United States any records pertaining to the investigation or prosecution of this case including, without limitation, any records that may be sought under the Freedom of Information Act, 5 U.S.C. § 552, or the Privacy Act of 1974, 5 U.S.C. § 552a.

  • WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of the Releasees accepting my application for a Season Pass and permitting my use of the lifts, ski runs, trails, terrain parks, race courses, restaurants, day lodge, parking, access roads and other ski area facilities (hereinafter “the premises”), I hereby agree as follows:

  • Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:

  • RELEASE OF LIABILITY, WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of THE RELEASEES allowing me to participate in wilderness activities, I hereby agree as follows:

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:  For certificates of insurance: 5 business days  For information on self-insurance or self-retention programs: 15 calendar days  For other requested documentation evidencing coverage: 15 calendar days  For additional insured and waiver of subrogation endorsements: 30 calendar days Notwithstanding the foregoing, if the Contractor shall have promptly requested the insurance documents from its broker or insurer and shall have thereafter diligently taken all steps necessary to obtain such documents from its insurer and submit them to OGS, OGS shall extend the time period for a reasonable period under the circumstances, but in no event shall the extension exceed 30 calendar days.

  • Required Confidentiality Claim Form This is a requirement of the TIPS Contract and is non-negotiable. TIPS provides the required TIPS Confidentiality Claim Form in the "Attachments" section of this solicitation. Vendor must execute this form by either signing and waiving any confidentiality claim, or designating portions of Vendor's proposal confidential. If Vendor considers any portion of Vendor's proposal to be confidential and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s) and orders, Vendor must have identified the claimed confidential materials through proper execution of the Confidentiality Claim Form. If TIPS receives a public information act or similar request, any responsive documentation not deemed confidential by you in this manner will be automatically released. For Vendor documents deemed confidential by you in this manner, TIPS will follow procedures of controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law, including Attorney General determination and opinion. Notwithstanding any other Vendor designation of Vendor's proposal as confidential or proprietary, Vendor’s submission of this proposal constitutes Vendor’s agreement that proper execution of the required TIPS Confidentiality Claim Form is the only way to assert any portion of Vendor's proposal as confidential.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!