Title Matters Seller agrees to share equally with Buyer the closing costs and the cost of a title insurance company's commitment for and policy of title insurance. Buyer shall pay for any lender’s/mortgagee’s/instrument holder’s title insurance coverage. The title insurance company will furnish a copy of the commitment for title insurance and copies of all of the exception documents referred to therein (hereafter collectively referred to as the “Title Commitment”) to Seller, Buyer, Buyer’s lender and the listing/selling broker as promptly as possible. The Title Commitment shall show a merchantable title vested in Seller, subject to easements, restrictions and protective covenants of record, right-of-way’s, setbacks, tenant rights, trees, fences, ordinances and regulations, unmatured and future assessments, restrictions and protective covenants of record, provided no forfeiture provisions as contained therein, encroachments and overlaps, zoning laws, ordinances and regulations, those exceptions which are standard to a policy of title insurance in the State of Kansas or as specified herein, and those matters attaching to the title by reason of Buyer taking title to the real property. Buyer shall have a period of five (5) days following receipt of the Title Commitment (the “Objection Period”) in which to examine the Title Commitment and advise Seller in writing of any objections ("Title Objections") the Buyer may have to Seller's title as shown in the Title Commitment. Seller shall then have a period of five (5) days in which to notify Buyer in writing of those Title Objections it elects to cure. In the event Seller elects to cure less than all of the Title Objections, Buyer shall have the right to terminate this Agreement by giving Seller written notice thereof within five (5) days of its receipt of Seller's notice, in which case the Xxxxxxx Money shall be returned to Buyer, and thereafter neither party shall have any further obligation hereunder. In the event Buyer does not terminate this Agreement, Seller shall have until Closing ("Cure Period") in which to cure the Title Objections the Seller has elected to cure, which the Buyer Agrees to extend for an additional 45 days in the event Seller has initiated a lawsuit to cure the title objection or objections. Title Objections may also be cured in accordance with applicable current titled standards in the Kansas Title Standards Handbook.
Title and Survey Matters 4.1 As soon as practicable after the Closing Date, Seller shall deliver to Purchaser a standard owner's policy of title insurance issued by the Title Insurer/Escrow Agent ("TITLE POLICY"). The Title Policy shall insure marketable title to the Property in the amount of the Purchase Price, free and clear of all liens, encumbrances and exceptions whatsoever, save and except only for those easements, restrictions and other matters of record affecting title to the Property which are Permitted Exceptions (as hereinafter defined).
4.2 Purchaser shall have until the end of the Due Diligence Period (as hereinafter defined) in which to review the title commitment and as-built survey to be delivered by Seller pursuant to Section 5.1, and to obtain any modifications, endorsements or other revisions to either the title commitment or the survey required by Purchaser, at Purchaser's cost. If Purchaser is unable to obtain any modification, endorsement or other revision to the title commitment or survey required by Purchaser, or if any items remain on the title commitment or survey which are not acceptable to Purchaser ("UNPERMITTED EXCEPTIONS"), then on or before the end of the Due Diligence Period, Purchaser shall so notify Seller (an "OBJECTION NOTICE"). Seller has a period of ten (10) days after the date of the Objection Notice in which Seller, using good faith efforts, shall attempt to remove such Unpermitted Matters or remedy same in a manner satisfactory to Purchaser in its sole and absolute discretion, or have the Title Insurer/Escrow Agent commit to insure against loss or damage that may be occasioned by such exceptions (in endorsements satisfactory to Purchaser). If Seller does not cure any Unpermitted Exceptions to Purchaser's satisfaction within such period, then Purchaser may either (a) terminate this Agreement by giving written notice to Seller of such termination not later than five (5) days following the end of the ten (10) day cure period, in which event the Xxxxxxx Money, and all interest earned thereon, shall be returned to Purchaser and neither party shall have any further obligations or liabilities hereunder or (b) accept such Unpermitted Exceptions. Any item not specified in the Objection Notice or subsequently accepted by Purchaser shall be a "PERMITTED EXCEPTION". Seller shall be obligated to remove prior to Closing all mortgages and other liens or encumbrances of a definite or ascertainable monetary amount, and if Seller fails to do so, Purchaser may elect to terminate this Agreement. At the Closing, and as a further condition of Purchaser's performance of its obligations hereunder, Seller shall cause the Title Insurer/Escrow Agent to deliver to Purchaser the Title Policy or a marked-up and signed commitment to deliver same.
Preliminary Matters 3.1. At least five (5) days prior to the pre-construction meeting described in Section 3.2, Contractor shall submit to Consultant for Consultant’s review and acceptance:
3.1.1. A progress schedule in the indicated form: Bar Chart Modified Critical Path Method (“CPM”) CPM Computerized CPM (CPM is interpreted to be generally as outlined in the Association of General Contractors (“AGC”) publication, “The Use of CPM in Construction.”) The progress schedule shall indicate the start and completion dates of the various stages of the Work, and shall show an activity network for the planning and execution of the Work. Included with the progress schedule shall be a narrative description of the progress schedule. The progress schedule must be updated monthly by Contractor, submitted as part of each Application for Payment, and must be acceptable to Consultant.
3.1.2. A preliminary schedule of Shop Drawing submissions; and
3.1.3. In a lump sum contract or in a contract that includes lump sum bid items of Work, a preliminary schedule of values for all of the Work that includes quantities and prices of items aggregating the Contract Price and that subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include a breakdown of labor, equipment, materials, and an appropriate amount of overhead and profit applicable to each item of Work, which amounts Contractor must confirm in writing at the time of submission. In addition, after award but prior to the submission of the progress schedule, Consultant, Contract Administrator, and Contractor shall meet with all utility owners and secure from them a schedule of utility relocation; provided, however, that neither Consultant nor Town shall be responsible for the nonperformance by the utility owners.
3.2. At a time specified by Consultant, but before Contractor starts the Work at the Project site, a conference attended by Contractor, Consultant, and others as deemed appropriate by Contract Administrator, will be held to discuss the schedules referred to in Section 3.1; to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment; and to establish a working understanding among the Parties as to the Work.
3.3. Within thirty-five (35) days from the Project Initiation Date set forth in the applicable Notice to Proceed, a conference attended by Contractor, Consultant, and others, as appropriate, will be held to finalize the schedules submitted in accordance with Section 3.1. Within forty-five
Copies of Documents Relating to Title Exceptions Copies of all recorded documents listed as exceptions to title or otherwise referred to in the Additional Mortgage Policy or title report delivered pursuant to clause (iv) or (v) above;
Title Review (a) On or after the Effective Date, Purchaser may order (i) a title commitment (the “Title Commitment”) from Land Services USA, Inc., as agent for (x) First American Title Insurance Company, (y) such other nationally recognized title insurance company mutually acceptable to Seller and Purchaser or (z) an alternate title insurance company (or alternate office) selected by Seller pursuant to Section 2.2(c) (the “Title Company”), together with complete and legible copies of all instruments and documents referred to therein as exceptions to title, and (ii) a survey of the Property from a reputable surveyor or surveying firm reasonably acceptable to the Title Company (the “Survey”) reflecting the total area of the Property, the location of all improvements, recorded easements and encroachments, if any, located thereon and all building and set back lines and plottable matters of record with respect thereto.
(b) Prior to the Expiration of the Due Diligence Period, Purchaser shall deliver written notice to Seller of any title matters, other than Permitted Exceptions, identified in the Title Commitment or shown on the Survey (or any supplements or updates thereto) which Purchaser finds objectionable (“Title Objections”). Seller shall have 5 Business Days from its receipt of such title objection notice from Purchaser to notify Purchaser whether Seller commits to cause such Title Objections to be removed from the land records or insured over (and with any such matters proposed to be insured over by the Title Company) at Closing, provided, however that Seller shall be obligated to remove or cause the removal from the land records of all Monetary Liens at or prior to Closing. Any matters set forth in the Title Commitment or Survey and not so objected to by Purchaser (other than Monetary Liens) shall be deemed to be Permitted Exceptions. If, for any reason, Seller is unable or unwilling to take such actions as may be required to remedy or remove from the land records any Title Objections (other than Monetary Liens) objected to by Purchaser, Seller shall give Purchaser notice thereof, it being understood and agreed that the failure of Seller to give such notice within 5 Business Days after receipt of Purchaser’s notice of objection shall be deemed an election by Seller not to remedy any such matters. If Seller shall be unable or unwilling to remedy any Title Objections (other than Monetary Liens) as to which Purchaser has objected, Purchaser may elect either (i) to terminate this Agreement by notice given to Seller within 5 Business Days following Purchaser’s receipt of Seller’s notice, whereupon the Deposit shall be refunded to Purchaser and neither party shall have any further obligations to the other hereunder, except for those obligations which expressly survive the termination of this Agreement or (ii) to proceed to Closing in accordance with the terms and conditions of this Agreement, notwithstanding such matters and without any abatement or reduction in the Purchase Price on account thereof. If any matter arises that was not previously disclosed in the Title Commitment or on the Survey (as same may have been updated), is discovered by Purchaser or by the Title Company and is added to such Title Commitment by the Title Company at or prior to Closing, Purchaser shall have five (5) Business Days (and the Closing shall be extended, if necessary) after Purchaser’s receipt of such updated Title Commitment showing the new title exception, together with a legible copy of any such new matter, to provide Seller with written notice of its objection to any such new title exception (each a “New Objection”, and collectively, the “New Objections”). If Seller does not elect to remove or cure New Objections prior to Closing (other than Monetary Liens, which Seller shall be obligated to cure), which such election shall be given by notice to Purchaser within 5 Business Days after Seller’s receipt of Purchaser’s notice setting forth such New Objections, Purchaser may, by written notice to Seller, either (i) agree to accept title subject to the exceptions which Seller is unable to remove or cause to be removed (in which case such exceptions shall be considered Permitted Exceptions) or (ii) terminate this Agreement, and in the latter event the Deposit and accrued interest thereon shall be returned to Purchaser, and thereafter, except for those obligations herein which are specifically stated to survive the termination of this Agreement, neither party shall have any further right, liability or obligation under this Agreement.
(c) In connection with the issuance of an ALTA 15-06 endorsement to the Title Policy at Closing, in the event that the Title Company is unable or unwilling to issue an ALTA 15-06 endorsement to the Title Policy at Closing upon terms and conditions acceptable to Seller, Seller shall have a one-time right (but not the obligation) to elect that the Title Policy be issued by an alternate title insurance company (or an alternate office of the Title Company) selected by Seller from the list of title insurance companies set forth on Schedule 2.2(c) attached hereto. In the event Seller so elects, Seller shall deliver written notice to Purchaser stating Seller’s election, Purchaser shall engage the alternate title insurance company (or alternate office of the Title Company, as applicable) selected by Seller for the purpose of issuing the Title Policy and Seller shall be responsible for 50% of any additional search and exam fees resulting from Seller’s exercise of its rights set forth in this Section 2.2(c).
Title Commitment (a) Purchaser has ordered a title insurance commitment with respect to the Real Property issued, by the Title Company (the “Title Commitment”). On or before July 25, 2013, Purchaser shall provide to Seller the Title Commitment, together with legible copies of the title exceptions listed thereon. On or before August 8, 2013 (the “Title Objection Date”), Purchaser shall notify Seller in writing, if there are (i) any monetary liens or other title exceptions that Purchaser objects to (“Title Objections”) or (ii) any Survey Objection. In the event Seller does not receive written notice of any Title Objections or Survey Objection by the Title Objection Date, TIME BEING OF THE ESSENCE, then Purchaser will be deemed to have accepted or waived such exceptions to title set forth on the Title Commitment as permitted exceptions (as accepted or waived by Purchaser, the “Permitted Exceptions”) and shall be deemed to have waived its right to object to any Survey Objection.
(b) After the Title Objection Date, if the Title Company raises any new exception to title to the Real Property, Purchaser’s counsel shall have five (5) Business Days after he or she receives notice of such exception (the “New Objection Date”) (or as promptly as possible prior to the Closing if such notice is received with less than five (5) Business Days prior to the Closing), to provide Seller with written notice if such exception constitutes a Title Objection. In the event Seller does not receive notice of such Title Objection by the New Objection Date, Purchaser will be deemed to have accepted the exceptions to title set forth on any updates to the Title Commitment as Permitted Exceptions.
(c) All taxes, water rates or charges, sewer rents and assessments, plus interest and penalties thereon, which on the Closing Date are liens against the Real Property and which Seller is obligated to pay and discharge will be credited against the Purchase Price (subject to the provision for apportionment of taxes, water rates and sewer rents herein contained) and shall not be deemed a Title Objection. If on the Closing Date there shall be security interests filed against the Real Property, such items shall not be Title Objections if (i) the personal property covered by such security interests are no longer in or on the Real Property, or (ii) such personal property is the property of a Tenant, and Seller executes and delivers an affidavit to such effect, or the security interest was filed more than five (5) year prior to the Closing Date and was not renewed.
(d) If on the Closing Date the Real Property shall be affected by any lien which, pursuant to the provisions of this Agreement, is required to be discharged or satisfied by Seller, Seller shall not be required to discharge or satisfy the same of record provided the money necessary to satisfy the lien is retained by the Title Company at Closing, and the Title Company either omits the lien as an exception from the title insurance commitment or insures against collection thereof from out of the Real Property, and a credit is given to Purchaser for the recording charges for a satisfaction or discharge of such lien.
(e) No franchise, transfer, inheritance, income, corporate or other tax open, levied or imposed against Seller or any former owner of the Property, that may be a lien against the Property on the Closing Date, shall be an objection to title if the Title Company insures against collection thereof from or out of the Real Property and/or the Improvements, and provided further that Seller deposits with the Title Company a sum of money or a parental guaranty reasonably acceptable to the Title Company and sufficient to secure a release of the Property from the lien thereof. If a search of title discloses judgments, bankruptcies, or other returns against other persons having names the same as or similar to that of Seller, Seller will deliver to Purchaser an affidavit stating that such judgments, bankruptcies or other returns do not apply to Seller, and such search results shall not be deemed Title Objections.
Title Evidence Seller agrees to share equally with Buyer the closing agent costs and the cost of a title insurance company’s commitment and standard ALTA form owner’s policy (except survey matters) to the Property, showing a marketable title vested in Seller, subject to easements, restrictions, covenants, and other matters of record. Any endorsements shall be paid solely by Buyer. The title evidence shall be presented to prospective Buyer on day of auction. Buyer acknowledges: (a) receipt of the title commitment prior to entering into this agreement; (b) review of the title commitment to the Buyer’s full satisfaction; and (c) waiver of any right to object to any exceptions listed therein. If Seller fails to satisfy all such title requirements imposed on Seller pursuant to title commitment, Buyer may, as its sole remedy and at Buyer’s election, either: (a) cancel this agreement and receive a return of Buyer’s xxxxxxx money and, in that event, this Agreement will be canceled and the parties will have no further obligations to each other; or (b) accept such title as Seller can deliver. Buyer waives any right to seek specific performance or to seek damages from Seller.
Title Objections On or before the expiration of the Inspection Period, herein defined, Purchaser, at Purchaser's expense, may obtain a title commitment issued by Escrow Agent, which shall provide a commitment to insure title to the Real Property on the full-coverage, standard, revised ALTA Owner's Policy of title insurance, Form B (the "Title Commitment") in the amount of the Purchase Price subject, however, to the Permitted Exceptions (to which Purchaser does not object), but without exception as to mechanics or similar liens, free and clear of any and all other mortgages, liens, judgments, leases, encumbrances, parties in possession, licenses, covenants, conditions, restrictions, easements, encroachments and any other matters of any nature affecting the title except as permitted in this Agreement. Within ten (10) days of receipt by Purchaser of the Title Commitment and the Survey, Purchaser shall advise Seller in writing of any objections to the Title Commitment (including any of the Permitted Exceptions) and the Survey and, if no objections are so submitted by Purchaser within the applicable time period, it shall be deemed that the Title Commitment and the Survey are satisfactory, and Purchaser has no objections thereto. If Purchaser does advise Seller in writing of any objections, Seller shall have ten (10) days after the receipt of such statement of objections in which to notify Purchaser as to whether it will cure or remove such objections, Seller having no obligation to do so. If Seller notifies Purchaser that it will not cure or remove such objections, or if Seller is deemed to have elected not to cure such objections, then within ten (10) days after the receipt by Purchaser of such notice from Seller, or upon expiration of such ten (10) day period, Purchaser shall elect to either (i) terminate this Agreement, whereupon this Agreement shall be of no further force and effect, the Xxxxxxx Money shall be returned to Purchaser, and no party hereto shall have any further rights, liabilities or obligations hereunder or (ii) waive such objections to Seller's title. Failure by Purchaser to elect either alternative within such ten (10) day period shall be deemed an election to waive such objections. If Seller sends no notice to Purchaser within said ten (10) days, Seller shall be deemed to have elected not to cure any such title objections.
Title Exceptions To the best of Borrower’s knowledge after due inquiry and investigation, none of the items shown in the schedule of exceptions to coverage in the title policy issued to and accepted by Lender contemporaneously with the execution of this Loan Agreement and insuring Lender’s interest in the Mortgaged Property will have a Material Adverse Effect on the (a) ability of Borrower to pay the Loan in full, (b) ability of Borrower to use all or any part of the Mortgaged Property in the manner in which the Mortgaged Property is being used on the Closing Date, except as set forth in Section 6.03, (c) operation of the Mortgaged Property, or (d) value of the Mortgaged Property.
Title and Survey Seller shall, at Seller's sole cost and expense, obtain and deliver to Purchaser for Purchaser's review a commitment for a standard owner's policy of title insurance along with a copy of each instrument listed as an exception thereon other than Seller's debt instruments (the "Title Commitment") on the Real Property issued by the Title Company. Seller has delivered to Purchaser a copy of the Existing Survey which Purchaser shall reimburse Seller for as provided in Section 4 hereof. During the Due Diligence Period, Seller shall obtain from the Title Company at Seller's sole cost and expense a survey endorsement and, if and to the extent available, contiguity, fairway and PUD endorsements. Purchaser may elect to receive an update to the Existing Survey (the "Updated Survey") by notifying Seller of such election in writing prior to November 6, 1997. If Purchaser so elects, Seller shall, at Purchaser's sole cost and expense, obtain and deliver to Purchaser for Purchaser's review the Updated Survey. Purchaser shall have until the later of November 6, 1997 and the date which is fifteen days after receipt of the Title Commitment and Existing Survey (such date being referred to as the "Title Review Date") for examination of Title Commitment and Existing Survey and the making of any objections thereto, said objections to be made in writing and delivered to Seller on or before the end of the Title Review Date. If Purchaser shall fail to make any objections on or before the Title Review Date, Purchaser shall be deemed to have accepted all exceptions to the Title Commitment shown on Schedule B, Section II, except for exceptions 1, 2, 3 and 4, and the form and substance of the Existing Survey and all matters shown thereon; all such exceptions and matters shall be included in the term "Permitted Exceptions" as used herein. In the event Purchaser elects to receive the Updated Survey, then Purchaser shall have until the Title Review Date for examination of the Updated Survey and the making of objections to matters shown thereon, such objections to be made in writing and delivered to Seller on or before the expiration of the Title Review Date. If Purchaser shall fail to make any such objections to the Updated Survey on or before such date, Purchaser shall be deemed to have accepted the form and substance of the Updated Survey and all matters shown thereon; all such exceptions and matters shall be included as Permitted Exceptions. If any objections to (i) the Title Commitment or Existing Survey or exceptions to title are made within the Title Review Period, or (ii) the Updated Survey are made before the date specified above, then Seller shall have the right, but not the obligation except as hereafter provided, to cure (by removal, endorsement or otherwise) such objections on or before the Closing Date in a manner reasonably acceptable to Purchaser. If the objections are not cured by Seller no later than five (5) days before the scheduled Closing Date, then Purchaser may as its only option, elect to either: (i) waive such objection and consummate the transaction contemplated by this Agreement; or (ii) terminate this Agreement, in which event the Xxxxxxx Money shall be returned to Purchaser and neither party shall have any further obligations to the other party except for the Surviving Obligations. Notwithstanding anything to the contrary contained in this Agreement, Seller shall be obligated to remove (or cause the Title Company to affirmatively insure over in a manner reasonably acceptable to Purchaser) (i) any deeds of trust, mortgages, and related loan documents securing any financing obtained by Seller, including, without limitation, the existing loan with Continental Bank, N.A. (the "Existing Loan"), (ii) any mechanic's or materialmen's liens relating to work done by or on behalf of Seller and (iii) any tax or judgment liens against Seller. Seller agrees to use best efforts to satisfy all of the requirements set forth in Schedule B - Section 1 of the Commitment at or prior to the Closing Date.
